Contract For Contractor And Homeowner for the United States

Contract For Contractor And Homeowner Template for United States

A legally binding agreement used in the United States between a licensed contractor and a residential property owner that outlines the scope of construction, renovation, or repair work to be performed. The document details project specifications, timeline, payment terms, warranties, and responsibilities of both parties while ensuring compliance with federal, state, and local construction laws and regulations.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Generate a Bespoke Document

1. Select your governing law:

2. Enter your key requirements:

3. Create your document to edit, review or download

Download a Standard Template

Get our United States-compliant Contract For Contractor And Homeowner

4.6 / 5

4.8 / 5

Alternatively: Run an advanced review of an existing
Contract For Contractor And Homeowner

Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

Upload your Doc

What is a Contract For Contractor And Homeowner?

The Contract For Contractor And Homeowner is essential for any residential construction or renovation project in the United States. This document serves as a crucial legal framework that protects both the contractor's and homeowner's interests by clearly defining project scope, costs, timelines, and responsibilities. It includes specific provisions for payment schedules, change orders, warranties, and dispute resolution, while ensuring compliance with various state-specific contractor licensing requirements and building codes. The contract is particularly important for managing risk, establishing clear expectations, and providing legal recourse if either party fails to meet their obligations.

What sections should be included in a Contract For Contractor And Homeowner?

1. Parties: Identification of contractor and homeowner with full legal names and addresses

2. Background: Context of the agreement and general purpose of the construction work

3. Definitions: Key terms used throughout the contract including 'Work', 'Project', 'Contract Documents', 'Change Order'

4. Scope of Work: Detailed description of services and work to be performed by the contractor

5. Payment Terms: Cost, payment schedule, and payment methods including provisions for final payment

6. Timeline: Project start date, completion date, and major milestones

7. Insurance and Liability: Required insurance coverage and liability assignments between parties

8. Warranties: Workmanship and materials warranties provided by the contractor

9. Termination: Conditions and procedures for contract termination by either party

What sections are optional to include in a Contract For Contractor And Homeowner?

1. Change Orders: Process and procedures for modifying scope of work during the project

2. Subcontractors: Terms regarding hiring and managing subcontractors, including liability and supervision requirements

3. Dispute Resolution: Mediation and arbitration procedures for resolving disputes between parties

4. Force Majeure: Terms covering unforeseen circumstances and events beyond parties' control

What schedules should be included in a Contract For Contractor And Homeowner?

1. Schedule A - Detailed Scope of Work: Comprehensive description of all work items and specifications

2. Schedule B - Payment Schedule: Detailed breakdown of payments and payment triggers

3. Schedule C - Project Timeline: Detailed project schedule with milestones and completion dates

4. Schedule D - Materials Specifications: Detailed list of materials to be used in the project

5. Appendix 1 - Contractor's Licenses: Copies of relevant licenses and certifications

6. Appendix 2 - Insurance Certificates: Proof of required insurance coverage

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Cost

Free to use

Relevant legal definitions

Clauses

Relevant Industries

Residential Construction
Home Improvement
Home Repair

Relevant Teams

Legal
Operations
Finance
Quality Assurance
Customer Relations

Relevant Roles

General Contractor
Project Manager
Construction Manager
Contract Administrator
Real Estate Agent

Industries

Fair Labor Standards Act (FLSA): Federal law establishing wage standards, overtime pay, recordkeeping, and child labor requirements affecting contractors and their employees

Occupational Safety and Health Act (OSHA): Federal regulations governing workplace safety and health standards that contractors must follow during construction

Americans with Disabilities Act (ADA): Federal law requiring consideration of accessibility standards in construction and renovation projects

Federal Tax Regulations: IRS requirements governing the classification and tax obligations of independent contractors

State Contractor Licensing Laws: State-specific requirements for contractor licensing, certification, and registration

State Building Codes: State-specific construction standards and requirements that must be met in all building projects

State Consumer Protection Laws: State regulations protecting homeowners from unfair practices and establishing contractor obligations

State Insurance Requirements: State-mandated insurance coverage requirements for contractors working on residential projects

Mechanics' Lien Laws: State-specific laws governing contractors' rights to place liens on property for unpaid work

Local Building Codes: Municipal construction standards and requirements specific to local jurisdictions

Local Permit Requirements: Municipal regulations regarding necessary permits and approvals for construction work

Zoning Regulations: Local laws governing land use and construction restrictions in specific areas

Contract Formation Laws: Legal principles governing contract creation, including offer, acceptance, and consideration requirements

Insurance Coverage Requirements: Mandatory insurance types including general liability, workers' compensation, and professional liability

Warranty Laws: State and federal regulations governing implied and express warranties on construction work

Payment Regulations: Laws governing payment schedules, progress payments, and financial terms in construction contracts

Environmental Regulations: Federal and state environmental protection requirements affecting construction projects

Consumer Rights Provisions: Laws establishing consumer rights including cancellation periods and required disclosures

Find the exact document you need

No matches found.

General Contractor And Subcontractor Agreement

U.S.-governed agreement between general contractor and subcontractor defining work scope, terms, and obligations in construction projects.

How Cambridge United Uses Genie AI to Speed Up Player Signings and Slash Legal Costs

Generate a Bespoke Document

Download a Standard Template

What is a Contract For Contractor And Homeowner?

What sections should be included in a Contract For Contractor And Homeowner?

What sections are optional to include in a Contract For Contractor And Homeowner?

What schedules should be included in a Contract For Contractor And Homeowner?

Authors

Alex Denne

Jurisdiction

Publisher

Document Type

Sector

Cost

Find the exact document you need

General Contractor And Subcontractor Agreement

General Contractor Contract With Subcontractor

Standard Contractors Agreement

Contract Agreement Between Owner And Contractor

Home Contractor Agreement

Contractor Warranty Agreement

Collaboration Agreement With Builder

Building Material Contract Agreement

Contractor Owner Agreement

Agreement Between Two Parties For Construction Contract

Pre Construction Purchase Agreement

Agreement Between Builder And Contractor

New Construction Purchase Agreement

Home Improvement Construction Contract

Collaboration Agreement For Construction Of Building

Construction Operating Agreement

Construction Company Contracts

General Contractor Subcontractor Agreement

Landscape Contractor Contract

Subcontract Agreement For Construction Work

Owner Subcontractor Agreement

Contract Between Builder And Client

Building Construction Contract Agreement

Agreement Between Two Contractors

Design And Construct Contract

Design Build Contract

Construction Labor Contract Agreement

Construction Collaboration Agreement

Agreement Between Land Owner And Builder

Letter Of Agreement For Construction Work

Management Building Contract

Construction Work Agreement

Commercial Construction Agreement

Owner Builder Agreement

General Contractor Contract With Owner

Construction Labor Agreement

Home Builder Contract

Building Construction Agreement

Builder Agreement

Residential Construction Contract

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security:

Templates

Contract Templates

Letter Templates

Policy Templates

Industries

Legal Services

Manufacturing

Construction

Solutions

Use Cases

Company Types

Comparisons

Business Categories

Teams

Information

Generate Legal Docs Free