The Turnkey Contract Agreement is a specialized contract format used in the Netherlands for projects requiring complete delivery of a fully operational facility or system. This comprehensive agreement, governed by Dutch law and compliant with the Burgerlijk Wetboek, is particularly suitable for complex projects where the client seeks single-point responsibility for the entire project scope. The document encompasses all aspects of project delivery, including design, procurement, construction, installation, testing, and commissioning. It's structured to align with Dutch construction regulations and industry standards, providing detailed provisions for risk allocation, quality assurance, and performance guarantees. The agreement is typically used for large-scale industrial, infrastructure, or commercial projects where the employer wants to minimize their operational involvement and transfer project delivery risk to the contractor.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
Alternatively...
1. Parties: Identification and details of the contracting parties (employer and contractor)
2. Background: Context of the agreement, project overview, and purpose
3. Definitions and Interpretation: Definitions of key terms and interpretation rules for the agreement
4. Scope of Work: Detailed description of the complete scope, including design, procurement, construction, and commissioning
5. Contract Price and Payment Terms: Fixed price, payment schedule, invoicing procedures, and payment conditions
6. Project Timeline: Commencement date, milestone dates, completion date, and provisions for extensions of time
7. Contractor's Obligations: Comprehensive list of contractor's responsibilities including design, construction, testing, and warranties
8. Employer's Obligations: Employer's responsibilities including site access, permits, and approvals
9. Design Responsibility: Allocation of design responsibility and approval procedures
10. Quality Assurance and Control: Quality standards, inspection procedures, and compliance requirements
11. Testing and Commissioning: Procedures for testing, commissioning, and performance verification
12. Completion and Handover: Conditions for substantial completion, final completion, and handover procedures
13. Defects Liability: Warranty period, rectification of defects, and post-completion obligations
14. Changes and Variations: Procedures for handling changes to scope, price, or timeline
15. Risk Allocation and Insurance: Distribution of risks and required insurance coverage
16. Force Majeure: Definition of force majeure events and consequences
17. Suspension and Termination: Rights and procedures for suspension and termination
18. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration
19. Governing Law and Jurisdiction: Specification of Dutch law as governing law and jurisdiction
20. General Provisions: Standard clauses including notices, assignments, and severability
1. Financing Arrangements: Required when project involves specific financing structures or requirements
2. Environmental Compliance: Detailed environmental obligations when project has significant environmental impact
3. Interface Management: Required when multiple contractors or stakeholders are involved
4. Technology License: Necessary when project involves specific technology licensing
5. Local Content Requirements: Required when project must meet local content or employment requirements
6. Export/Import Requirements: Necessary for projects involving international procurement
7. Performance Guarantees: Detailed performance parameters when specific output guarantees are required
8. Training and Knowledge Transfer: Required when operator training is part of scope
1. Schedule 1 - Technical Specifications: Detailed technical requirements and performance specifications
2. Schedule 2 - Project Schedule: Detailed timeline with milestones and critical path
3. Schedule 3 - Price Breakdown: Detailed breakdown of contract price and payment milestones
4. Schedule 4 - Site Information: Site details, geotechnical data, and existing conditions
5. Schedule 5 - Forms and Procedures: Standard forms for variations, certificates, and notices
6. Schedule 6 - Testing and Commissioning Procedures: Detailed procedures for testing and commissioning
7. Schedule 7 - Drawings and Design Documents: List of drawings and design documents
8. Schedule 8 - Permits and Approvals: List of required permits and responsible parties
9. Schedule 9 - Key Personnel: List of key personnel from both parties
10. Schedule 10 - Insurance Requirements: Detailed insurance requirements and coverage limits
11. Appendix A - Performance Tests: Detailed procedures for performance testing
12. Appendix B - Quality Assurance Plan: Detailed quality management procedures
13. Appendix C - HSE Requirements: Health, safety, and environmental requirements
Authors
Find the document you need
Construction Contractor Agreement
A Dutch law-governed agreement between a construction contractor and client for construction projects in the Netherlands, incorporating local building regulations and industry standards.
Download
Project Financing Agreement
A Dutch law-governed agreement structuring the financing of large-scale projects through debt and equity, with repayment primarily dependent on project cash flows.
Download
Non Disclosure Agreement For Design Work
Dutch law-compliant NDA specifically crafted for protecting confidential design work and related intellectual property.
Download
Consortium Partnership Agreement
Dutch law-governed agreement establishing terms and conditions for multi-party consortium partnerships, including governance, resources, and risk allocation.
Download
Design Build Contract
Dutch law-governed contract combining design and construction responsibilities under a single contractor, incorporating Dutch Civil Code provisions and construction regulations.
Download
Turnkey Contract Agreement
A Dutch law-governed agreement for the complete delivery of a turnkey project, covering all aspects from design through to commissioning with full contractor responsibility.
Download
Renovation Agreement
Dutch law-governed agreement setting out terms and conditions for property renovation works, including scope, pricing, and obligations of contractor and owner.
Download
Demolition Agreement
Dutch law agreement establishing terms and conditions for demolition works, including safety, environmental compliance, and contractor obligations.
Download
Remodeling Contractor Agreement
A Dutch law-governed agreement between a contractor and property owner specifying terms and conditions for renovation or remodeling work.
Download
Project Management Contract
Dutch law-governed agreement establishing terms and conditions for project management services, defining scope, responsibilities, and deliverables between client and project manager.
Download
Joint Development Agreement
Dutch law agreement governing collaborative development projects between multiple parties, establishing rights, responsibilities, and project governance.
Download
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your data is private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
