The Construction Short Form Contract is specifically designed for use in the Indian construction industry where a simplified yet comprehensive agreement is required. It is particularly suitable for small to medium-sized construction projects where the full complexity of a standard construction contract would be unnecessary or burdensome. This document type incorporates all essential elements required under Indian law, including provisions mandated by the Indian Contract Act, 1872, and construction-specific legislation, while maintaining a practical and accessible format. It is commonly used for residential construction, small commercial projects, renovation works, and other construction activities where the scope and risks are well-defined and manageable. The contract balances the need for legal protection with practical usability, making it an efficient tool for straightforward construction projects in the Indian market.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification of the contracting parties (Owner/Employer and Contractor) with full legal names and addresses
2. Background: Brief context of the construction project and purpose of the agreement
3. Definitions: Key terms used throughout the contract, including technical construction terminology
4. Scope of Work: Clear description of the construction work to be performed by the Contractor
5. Contract Price and Payment Terms: Amount payable, payment schedule, and payment conditions
6. Timeline and Completion: Project schedule, completion date, and provisions for extensions of time
7. Contractor's Obligations: Key responsibilities including quality standards, safety measures, and compliance requirements
8. Owner's Obligations: Site access, permits, approvals, and other owner responsibilities
9. Materials and Workmanship: Quality standards, specifications, and approval requirements for materials
10. Variations: Process for handling changes to scope, price, or timeline
11. Defects Liability: Contractor's responsibilities for rectifying defects during the liability period
12. Insurance and Indemnity: Required insurance coverage and indemnification obligations
13. Termination: Grounds and process for contract termination by either party
14. Dispute Resolution: Process for resolving disputes, including arbitration provisions
15. Governing Law: Specification of Indian law as governing law and jurisdiction
1. Performance Security: Required for larger projects where contractor must provide bank guarantee or performance bond
2. Subcontracting: Include when subcontracting will be permitted, specifying conditions and approval requirements
3. Force Majeure: Detailed force majeure provisions for projects in high-risk areas or longer durations
4. Environmental Compliance: Additional environmental obligations for projects with significant environmental impact
5. Site Conditions: Detailed provisions about site conditions when working in challenging or uncertain terrain
6. Quality Assurance: Detailed quality control procedures for complex technical projects
7. Testing and Commissioning: Specific testing requirements for projects involving mechanical or electrical installations
8. Intellectual Property: Required when design elements or proprietary methods are involved
9. Liquidated Damages: Specific compensation for delay or performance failures in time-critical projects
1. Schedule 1 - Scope of Work: Detailed technical specifications and drawings of the construction work
2. Schedule 2 - Bill of Quantities: Itemized list of quantities and rates for the construction work
3. Schedule 3 - Project Timeline: Detailed project schedule with milestones and completion dates
4. Schedule 4 - Payment Schedule: Detailed breakdown of payment terms, installments, and conditions
5. Schedule 5 - Site Details: Site plan, access points, and relevant site conditions
6. Schedule 6 - Material Specifications: Detailed specifications for construction materials to be used
7. Schedule 7 - Forms and Certificates: Standard forms for variations, completion certificates, and other project documents
8. Schedule 8 - Insurance Requirements: Detailed insurance coverage requirements and minimum amounts
9. Appendix A - Safety Standards: Safety protocols and requirements for the construction site
10. Appendix B - Quality Control Procedures: Detailed quality control and testing procedures
Relevant legal definitions
Agreement
Applicable Laws
Approved
Bill of Quantities
Commencement Date
Completion Certificate
Completion Date
Contract Price
Contract Documents
Contractor
Day
Defects Liability Period
Drawings
Employer
Extension of Time
Force Majeure
Good Industry Practice
Liquidated Damages
Materials
Milestone
Notice
Owner
Party/Parties
Payment Certificate
Project
Project Manager
Project Site
Retention Money
Schedule
Scope of Work
Site
Specifications
Subcontractor
Substantial Completion
Time for Completion
Variation
Works
Applicable Laws
Approved
Bill of Quantities
Commencement Date
Completion Certificate
Completion Date
Contract Price
Contract Documents
Contractor
Day
Defects Liability Period
Drawings
Employer
Extension of Time
Force Majeure
Good Industry Practice
Liquidated Damages
Materials
Milestone
Notice
Owner
Party/Parties
Payment Certificate
Project
Project Manager
Project Site
Retention Money
Schedule
Scope of Work
Site
Specifications
Subcontractor
Substantial Completion
Time for Completion
Variation
Works
Clauses
Scope of Work
Contract Price
Payment Terms
Project Timeline
Materials and Equipment
Quality Standards
Health and Safety
Site Access and Conditions
Contractor Obligations
Owner Obligations
Variations
Extension of Time
Force Majeure
Insurance
Indemnification
Defects Liability
Testing and Inspection
Warranties
Permits and Approvals
Labor and Employment
Subcontracting
Environmental Compliance
Performance Security
Retention
Liquidated Damages
Dispute Resolution
Termination
Notices
Assignment
Governing Law
Entire Agreement
Contract Price
Payment Terms
Project Timeline
Materials and Equipment
Quality Standards
Health and Safety
Site Access and Conditions
Contractor Obligations
Owner Obligations
Variations
Extension of Time
Force Majeure
Insurance
Indemnification
Defects Liability
Testing and Inspection
Warranties
Permits and Approvals
Labor and Employment
Subcontracting
Environmental Compliance
Performance Security
Retention
Liquidated Damages
Dispute Resolution
Termination
Notices
Assignment
Governing Law
Entire Agreement
Relevant Industries
Real Estate Development
Commercial Construction
Residential Construction
Industrial Construction
Infrastructure Development
Hospitality
Retail
Healthcare
Education
Manufacturing
Relevant Teams
Legal
Operations
Construction
Project Management
Commercial
Procurement
Risk & Compliance
Technical Services
Property Development
Facilities Management
Relevant Roles
Construction Manager
Project Manager
Contract Administrator
Legal Counsel
Procurement Manager
Site Engineer
Quantity Surveyor
Architect
Commercial Manager
Operations Director
Risk Manager
Facilities Manager
Development Manager
Construction Director
Technical Director
Find the exact document you need
Lien Contract
An Indian law-governed agreement establishing a lien right over specified property as security for an underlying obligation.
find out more
Labour Contract Form
A standardized employment agreement compliant with Indian labor laws, establishing terms and conditions of employment between employer and employee.
find out more
House Wiring Contract
An Indian law-governed contract for electrical wiring installation services, specifying technical requirements, safety standards, and compliance with Indian electrical regulations.
find out more
Handyman Maintenance Contract
An Indian law-governed agreement between a handyman/maintenance service provider and property owner/manager, outlining maintenance services, terms, and obligations.
find out more
General Contract
A versatile contract template under Indian law that establishes formal business relationships between parties, compliant with the Indian Contract Act and related legislation.
find out more
Contractor Non Compete Agreement
An Indian law-compliant agreement restricting a contractor's competitive activities during their engagement period, protecting company interests while maintaining enforceability under Section 27 of the Indian Contract Act.
find out more
Contractor Lien Release
An Indian legal document where a contractor waives their right to place a lien on a property after receiving payment for work performed or materials supplied.
find out more
Contract With Builder
An Indian law-governed agreement between property owner and builder for construction works, compliant with RERA and construction regulations.
find out more
Contractors Agreement Form
An Indian law-governed agreement establishing terms and conditions between a hiring entity and a contractor, defining their professional relationship and mutual obligations.
find out more
Conditions Of Contract For (Construction)
Standard construction contract conditions template under Indian law governing rights, obligations, and procedures for construction projects in India.
find out more
Construction Agreement Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction works, including scope, payments, and compliance requirements.
find out more
Basic Independent Contractor Agreement
An Indian law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining service scope, payment terms, and contractor status.
find out more
Architect Contract Agreement
An Indian law-governed agreement between an architect/architectural firm and client, defining architectural services, fees, and mutual obligations.
find out more
Simple Contract Labor Agreement
An Indian law-compliant agreement between a Principal Employer and Contractor for the provision and management of contract labor services.
find out more
Private Security Contract
An Indian law-governed agreement for private security services provision, compliant with PSARA 2005 and related regulations.
find out more
Payment Contract Agreement
An Indian law-governed agreement establishing payment terms, schedules, and obligations between parties, ensuring compliant and secure monetary transactions.
find out more
Contractor Work Contract
An India-compliant Contractor Work Contract establishing terms and conditions for independent contractor services, including scope, payment, and deliverables.
find out more
Building Construction Labour Contract Agreement
An Indian jurisdiction labor contract agreement for construction projects, establishing terms between principal employers and labor contractors while ensuring compliance with local construction and labor laws.
find out more
Developer Contractor Agreement
An Indian law-governed agreement establishing terms for engaging an independent developer contractor, including service scope, payments, and IP rights.
find out more
Standard Form Of Agreement Between Owner And Contractor
An Indian law-governed agreement between property owner and contractor defining construction project terms, obligations, and deliverables.
find out more
Turnkey Contract
An Indian law-governed contract for the complete design, construction, and delivery of a fully operational facility, where the contractor assumes total responsibility from design through commissioning.
find out more
Time And Materials Contract
An Indian law-governed agreement for charging based on actual time spent and materials used in project delivery, including rates, tracking, and approval processes.
find out more
Standard Renovation Contract
An Indian law-governed contract establishing terms and conditions for property renovation works between owners and contractors.
find out more
Swimming Pool Contract
An Indian law-governed contract for swimming pool construction and installation, detailing specifications, responsibilities, and compliance requirements.
find out more
Suppliers Contract Agreement
An Indian law-governed agreement establishing terms and conditions between a purchaser and supplier for the provision of goods or services.
find out more
Service Contract Proposal
An Indian law-compliant Service Contract Proposal template outlining service arrangements, terms, and obligations between parties under Indian jurisdiction.
find out more
Residential Solar Installation Contract
An Indian law-governed contract for residential solar power system installation, covering technical specifications, warranties, and regulatory compliance.
find out more
Restoration Contract
An Indian law-governed contract specifying terms and conditions for property restoration work, including scope, specifications, timelines, and compliance requirements.
find out more
Receipt Contract
A legally binding document under Indian law that provides formal evidence of a financial transaction or transfer of goods/services, compliant with Indian Contract Act and GST regulations.
find out more
Real Estate Contractor Agreement
An Indian law-governed agreement between property owner/developer and contractor establishing terms and conditions for construction services, including scope, payments, and compliance requirements.
find out more
Proposal And Contract
An Indian law-governed document combining a business proposal with binding contractual terms, establishing commercial and legal parameters for business relationships.
find out more
Owner's Representative Contract
An Indian law-governed agreement appointing a representative to act on behalf of a property owner, defining their authority, responsibilities, and compensation.
find out more
Masonry Contract
An Indian law-governed contract establishing terms and conditions for masonry construction work, including quality standards, specifications, and compliance requirements.
find out more
Marketing Agreement Contract
An Indian law-governed agreement establishing terms between a marketing service provider and client for marketing services delivery, including scope, payments, and compliance requirements.
find out more
Lump Sum Contract
An Indian law-governed fixed-price contract establishing terms for project delivery at a predetermined lump sum amount, with defined scope and milestone-based payments.
find out more
Insurance Agency Agreement
An Indian law-governed agreement establishing the relationship between an insurance company and its agent, compliant with IRDAI regulations.
find out more
Labour Only Subcontractor Agreement
Indian law-compliant agreement template for engaging labor-only subcontractors, ensuring compliance with local labor regulations and statutory requirements.
find out more
Kitchen Renovation Contract
An Indian law-governed contract for kitchen renovation projects, defining scope, terms, and obligations between contractors and property owners.
find out more
Kitchen Contract
An Indian law-governed agreement for kitchen construction or renovation services, outlining project specifications, terms, and obligations of all parties involved.
find out more
Labour Supply Contract
An Indian law-governed agreement between a labor contractor and principal employer for the supply and management of contract workers.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)