The Restoration Contract serves as a critical legal instrument in India for projects involving the restoration, rehabilitation, or renovation of buildings and structures. This document type is essential when engaging professional contractors for significant restoration work, whether for heritage buildings, commercial properties, or residential structures. The contract, governed by Indian law, particularly the Indian Contract Act, 1872, and various construction and heritage preservation regulations, establishes clear parameters for the restoration project. It typically includes detailed specifications of work, quality standards, timelines, payment terms, and compliance requirements. The Restoration Contract is particularly important in protecting both parties' interests while ensuring the restoration work meets all necessary technical, legal, and regulatory standards in the Indian context.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification of the property owner/client and the restoration contractor, including their complete legal names, addresses, and registration details
2. Background: Context of the restoration project, including brief history of the property and reason for restoration
3. Definitions: Definitions of technical terms, industry-specific terminology, and key contract terms used throughout the document
4. Scope of Work: Detailed description of the restoration work to be performed, including specific areas to be restored and expected outcomes
5. Contract Price and Payment Terms: Total contract value, payment schedule, terms of payment, and handling of additional costs
6. Timeline and Completion: Project schedule, milestones, completion date, and provisions for extensions
7. Contractor's Obligations: Responsibilities of the contractor including quality standards, safety measures, and compliance requirements
8. Client's Obligations: Responsibilities of the client including access provision, approvals, and necessary documentation
9. Materials and Workmanship: Standards for materials used, quality requirements, and workmanship expectations
10. Warranties and Guarantees: Warranties for the restoration work, duration of guarantee period, and remedy procedures
11. Insurance and Indemnity: Insurance requirements and indemnification provisions
12. Termination: Grounds for termination, notice requirements, and consequences of termination
13. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
14. Governing Law: Specification of Indian law as governing law and jurisdiction details
1. Heritage Conservation Requirements: Include when working on heritage buildings or structures protected under preservation laws
2. Environmental Protection Measures: Include when restoration work may have significant environmental impact
3. Specialized Equipment: Include when specific specialized equipment is required for the restoration work
4. Subcontractor Provisions: Include when subcontractors will be engaged for specialized restoration work
5. Force Majeure: Include detailed force majeure provisions for projects in areas prone to natural disasters or other unforeseen events
6. Intellectual Property Rights: Include when restoration involves unique designs or innovative techniques
7. Storage and Security: Include when valuable materials or artifacts need to be stored during restoration
1. Schedule A - Detailed Scope of Work: Comprehensive technical specifications of all restoration work to be performed
2. Schedule B - Site Plans and Drawings: Architectural drawings, site plans, and detailed restoration drawings
3. Schedule C - Bill of Quantities: Itemized list of materials, quantities, and their costs
4. Schedule D - Project Timeline: Detailed project schedule with milestones and completion dates
5. Schedule E - Payment Schedule: Detailed breakdown of payment terms, installments, and payment milestones
6. Schedule F - Material Specifications: Detailed specifications of materials to be used in restoration
7. Schedule G - Quality Control Procedures: Standards and procedures for quality control and testing
8. Appendix 1 - Required Permits and Approvals: List of necessary permits and regulatory approvals
9. Appendix 2 - Safety Protocol: Detailed safety procedures and requirements for the restoration work
Relevant legal definitions
Agreement
Applicable Laws
Approved Drawings
As-Built Drawings
Bill of Quantities
Completion Certificate
Contract Price
Contractor
Defects Liability Period
Effective Date
Force Majeure Event
Good Industry Practice
Heritage Structure
Materials
Original Features
Project
Project Manager
Project Site
Quality Control Plan
Restoration Work
Restoration Methodology
Schedule of Works
Scope of Work
Site Access
Specifications
Substantial Completion
Technical Standards
Timeline
Variations
Work Order
Workmanship
Client
Consultant
Contingency Fund
Defect
Extension of Time
Interim Certificate
Milestone
Notice
Permits
Practical Completion
Progress Report
Site Conditions
Subcontractor
Testing
Warranties
Applicable Laws
Approved Drawings
As-Built Drawings
Bill of Quantities
Completion Certificate
Contract Price
Contractor
Defects Liability Period
Effective Date
Force Majeure Event
Good Industry Practice
Heritage Structure
Materials
Original Features
Project
Project Manager
Project Site
Quality Control Plan
Restoration Work
Restoration Methodology
Schedule of Works
Scope of Work
Site Access
Specifications
Substantial Completion
Technical Standards
Timeline
Variations
Work Order
Workmanship
Client
Consultant
Contingency Fund
Defect
Extension of Time
Interim Certificate
Milestone
Notice
Permits
Practical Completion
Progress Report
Site Conditions
Subcontractor
Testing
Warranties
Clauses
Scope of Work
Payment Terms
Project Timeline
Quality Standards
Materials and Workmanship
Health and Safety
Insurance
Indemnification
Warranties and Guarantees
Site Access and Security
Permits and Approvals
Environmental Protection
Heritage Conservation
Variation Orders
Force Majeure
Termination
Dispute Resolution
Confidentiality
Intellectual Property
Labor Compliance
Subcontracting
Documentation and Records
Testing and Inspection
Defects Liability
Completion and Handover
Risk Allocation
Representations and Warranties
Assignment and Novation
Notices
Governing Law
Liquidated Damages
Performance Security
Progress Reporting
Quality Control
Payment Terms
Project Timeline
Quality Standards
Materials and Workmanship
Health and Safety
Insurance
Indemnification
Warranties and Guarantees
Site Access and Security
Permits and Approvals
Environmental Protection
Heritage Conservation
Variation Orders
Force Majeure
Termination
Dispute Resolution
Confidentiality
Intellectual Property
Labor Compliance
Subcontracting
Documentation and Records
Testing and Inspection
Defects Liability
Completion and Handover
Risk Allocation
Representations and Warranties
Assignment and Novation
Notices
Governing Law
Liquidated Damages
Performance Security
Progress Reporting
Quality Control
Relevant Industries
Construction
Real Estate
Heritage Conservation
Architecture
Interior Design
Government and Public Sector
Cultural Institutions
Religious Institutions
Hospitality
Education
Relevant Teams
Legal
Facilities Management
Project Management
Construction
Procurement
Quality Assurance
Risk Management
Finance
Operations
Property Management
Heritage Conservation
Technical Services
Compliance
Relevant Roles
Facility Manager
Property Manager
Project Manager
Construction Manager
Heritage Conservation Specialist
Architectural Conservator
Restoration Architect
Building Surveyor
Contract Manager
Legal Counsel
Quality Control Manager
Site Supervisor
Procurement Manager
Cost Estimator
Conservation Officer
Find the exact document you need
Lien Contract
An Indian law-governed agreement establishing a lien right over specified property as security for an underlying obligation.
find out more
Labour Contract Form
A standardized employment agreement compliant with Indian labor laws, establishing terms and conditions of employment between employer and employee.
find out more
House Wiring Contract
An Indian law-governed contract for electrical wiring installation services, specifying technical requirements, safety standards, and compliance with Indian electrical regulations.
find out more
Handyman Maintenance Contract
An Indian law-governed agreement between a handyman/maintenance service provider and property owner/manager, outlining maintenance services, terms, and obligations.
find out more
General Contract
A versatile contract template under Indian law that establishes formal business relationships between parties, compliant with the Indian Contract Act and related legislation.
find out more
Contractor Non Compete Agreement
An Indian law-compliant agreement restricting a contractor's competitive activities during their engagement period, protecting company interests while maintaining enforceability under Section 27 of the Indian Contract Act.
find out more
Contractor Lien Release
An Indian legal document where a contractor waives their right to place a lien on a property after receiving payment for work performed or materials supplied.
find out more
Contract With Builder
An Indian law-governed agreement between property owner and builder for construction works, compliant with RERA and construction regulations.
find out more
Contractors Agreement Form
An Indian law-governed agreement establishing terms and conditions between a hiring entity and a contractor, defining their professional relationship and mutual obligations.
find out more
Conditions Of Contract For (Construction)
Standard construction contract conditions template under Indian law governing rights, obligations, and procedures for construction projects in India.
find out more
Construction Agreement Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction works, including scope, payments, and compliance requirements.
find out more
Basic Independent Contractor Agreement
An Indian law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining service scope, payment terms, and contractor status.
find out more
Architect Contract Agreement
An Indian law-governed agreement between an architect/architectural firm and client, defining architectural services, fees, and mutual obligations.
find out more
Simple Contract Labor Agreement
An Indian law-compliant agreement between a Principal Employer and Contractor for the provision and management of contract labor services.
find out more
Private Security Contract
An Indian law-governed agreement for private security services provision, compliant with PSARA 2005 and related regulations.
find out more
Payment Contract Agreement
An Indian law-governed agreement establishing payment terms, schedules, and obligations between parties, ensuring compliant and secure monetary transactions.
find out more
Contractor Work Contract
An India-compliant Contractor Work Contract establishing terms and conditions for independent contractor services, including scope, payment, and deliverables.
find out more
Building Construction Labour Contract Agreement
An Indian jurisdiction labor contract agreement for construction projects, establishing terms between principal employers and labor contractors while ensuring compliance with local construction and labor laws.
find out more
Developer Contractor Agreement
An Indian law-governed agreement establishing terms for engaging an independent developer contractor, including service scope, payments, and IP rights.
find out more
Standard Form Of Agreement Between Owner And Contractor
An Indian law-governed agreement between property owner and contractor defining construction project terms, obligations, and deliverables.
find out more
Turnkey Contract
An Indian law-governed contract for the complete design, construction, and delivery of a fully operational facility, where the contractor assumes total responsibility from design through commissioning.
find out more
Time And Materials Contract
An Indian law-governed agreement for charging based on actual time spent and materials used in project delivery, including rates, tracking, and approval processes.
find out more
Standard Renovation Contract
An Indian law-governed contract establishing terms and conditions for property renovation works between owners and contractors.
find out more
Swimming Pool Contract
An Indian law-governed contract for swimming pool construction and installation, detailing specifications, responsibilities, and compliance requirements.
find out more
Suppliers Contract Agreement
An Indian law-governed agreement establishing terms and conditions between a purchaser and supplier for the provision of goods or services.
find out more
Service Contract Proposal
An Indian law-compliant Service Contract Proposal template outlining service arrangements, terms, and obligations between parties under Indian jurisdiction.
find out more
Residential Solar Installation Contract
An Indian law-governed contract for residential solar power system installation, covering technical specifications, warranties, and regulatory compliance.
find out more
Restoration Contract
An Indian law-governed contract specifying terms and conditions for property restoration work, including scope, specifications, timelines, and compliance requirements.
find out more
Receipt Contract
A legally binding document under Indian law that provides formal evidence of a financial transaction or transfer of goods/services, compliant with Indian Contract Act and GST regulations.
find out more
Real Estate Contractor Agreement
An Indian law-governed agreement between property owner/developer and contractor establishing terms and conditions for construction services, including scope, payments, and compliance requirements.
find out more
Proposal And Contract
An Indian law-governed document combining a business proposal with binding contractual terms, establishing commercial and legal parameters for business relationships.
find out more
Owner's Representative Contract
An Indian law-governed agreement appointing a representative to act on behalf of a property owner, defining their authority, responsibilities, and compensation.
find out more
Masonry Contract
An Indian law-governed contract establishing terms and conditions for masonry construction work, including quality standards, specifications, and compliance requirements.
find out more
Marketing Agreement Contract
An Indian law-governed agreement establishing terms between a marketing service provider and client for marketing services delivery, including scope, payments, and compliance requirements.
find out more
Lump Sum Contract
An Indian law-governed fixed-price contract establishing terms for project delivery at a predetermined lump sum amount, with defined scope and milestone-based payments.
find out more
Insurance Agency Agreement
An Indian law-governed agreement establishing the relationship between an insurance company and its agent, compliant with IRDAI regulations.
find out more
Labour Only Subcontractor Agreement
Indian law-compliant agreement template for engaging labor-only subcontractors, ensuring compliance with local labor regulations and statutory requirements.
find out more
Kitchen Renovation Contract
An Indian law-governed contract for kitchen renovation projects, defining scope, terms, and obligations between contractors and property owners.
find out more
Kitchen Contract
An Indian law-governed agreement for kitchen construction or renovation services, outlining project specifications, terms, and obligations of all parties involved.
find out more
Labour Supply Contract
An Indian law-governed agreement between a labor contractor and principal employer for the supply and management of contract workers.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)