The Turnkey Contract is a specialized agreement used when an organization requires a complete, operational facility or project delivered by a single contractor who assumes full responsibility for all aspects from design through commissioning. This contract type is particularly relevant in India's rapidly developing infrastructure and industrial sectors, where complex projects require comprehensive execution responsibility and clear accountability. The document incorporates essential elements of Indian contract law, construction regulations, and industry standards, while addressing specific requirements for permits, approvals, and compliance with local authorities. It is designed to protect both the employer's interests in receiving a fully functional facility and the contractor's rights in managing project execution. The contract includes detailed provisions for scope, pricing, timelines, quality standards, testing, and acceptance criteria, making it suitable for large-scale industrial, infrastructure, or commercial projects where single-point responsibility is crucial.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification of the parties entering into the contract - employer and contractor
2. Background: Context of the project and purpose of the agreement
3. Definitions and Interpretation: Definitions of key terms and rules for contract interpretation
4. Scope of Work: Detailed description of the complete project scope, including design, procurement, construction, and commissioning
5. Contract Price and Payment Terms: Total contract value, payment schedule, milestones, and payment conditions
6. Project Timeline: Project schedule, key milestones, completion dates, and extension provisions
7. Contractor's Obligations: Comprehensive list of contractor responsibilities including design, construction, testing, and commissioning
8. Employer's Obligations: Responsibilities of the employer including site access, permits, and approvals
9. Quality and Standards: Required quality standards, specifications, and acceptance criteria
10. Testing and Commissioning: Procedures for testing, commissioning, and acceptance of the completed facility
11. Warranties and Guarantees: Performance guarantees, warranties, and defect liability provisions
12. Risk and Insurance: Risk allocation, required insurance coverage, and indemnification
13. Force Majeure: Definition of force majeure events and their consequences
14. Changes and Variations: Procedures for handling changes to scope, price, or timeline
15. Termination: Grounds and procedures for contract termination
16. Dispute Resolution: Mechanisms for resolving disputes including arbitration procedures
17. Governing Law and Jurisdiction: Applicable law and jurisdiction for the contract
1. Performance Security: Requirements for performance bonds or bank guarantees, used when additional financial security is needed
2. Intellectual Property Rights: IP ownership and licensing provisions, important when proprietary technology is involved
3. Environmental Compliance: Specific environmental obligations, necessary for projects with significant environmental impact
4. Local Content Requirements: Provisions for local sourcing and content, relevant when required by local regulations
5. Interface Management: Procedures for managing interfaces with other contractors, needed for complex projects
6. Training and Knowledge Transfer: Requirements for training employer's personnel, important when operational handover is critical
7. Spare Parts and Maintenance: Provisions for long-term maintenance and spare parts supply, relevant for operational continuity
8. Step-in Rights: Employer's rights to step in and take control, used in critical infrastructure projects
9. Liquidated Damages: Specific compensation for delay or performance shortfall, when precise damage calculation is needed
1. Technical Specifications: Detailed technical requirements and performance specifications
2. Price Schedule: Detailed breakdown of contract price, unit rates, and bill of quantities
3. Project Schedule: Detailed project timeline with milestones and critical path
4. Performance Tests: Detailed testing procedures and acceptance criteria
5. Site Information: Site details, conditions, and access requirements
6. Forms of Guarantees: Templates for various guarantees and bonds
7. Insurance Requirements: Detailed insurance coverage requirements
8. List of Approved Subcontractors: Pre-approved subcontractors and vendors
9. Health and Safety Requirements: Detailed HSE requirements and procedures
10. Quality Assurance Plan: Detailed quality management procedures and requirements
11. List of Permits and Approvals: Required permits and party responsible for obtaining them
12. Equipment List: Detailed list of equipment to be supplied and installed
Relevant legal definitions
Acceptance Certificate
Applicable Laws
Approved
As-Built Drawings
Background IP
Base Price
Bill of Quantities
Change Order
Commissioning
Completion Certificate
Confidential Information
Contract Documents
Contract Price
Contractor
Contractor's Equipment
Defects Liability Period
Deliverables
Design Documents
Effective Date
Employer
Employer's Requirements
Final Acceptance
Force Majeure Event
Good Industry Practice
Governmental Authority
Guarantee Test
Intellectual Property Rights
Interface Points
Key Personnel
Liquidated Damages
Milestone
Notice to Proceed
Performance Guarantee
Performance Security
Performance Tests
Project
Project Schedule
Provisional Acceptance
Punch List
Quality Assurance Plan
Site
Specifications
Subcontractor
Substantial Completion
Taking Over
Technical Documents
Technology License
Time for Completion
Variation
Warranty Period
Work
Working Day
Applicable Laws
Approved
As-Built Drawings
Background IP
Base Price
Bill of Quantities
Change Order
Commissioning
Completion Certificate
Confidential Information
Contract Documents
Contract Price
Contractor
Contractor's Equipment
Defects Liability Period
Deliverables
Design Documents
Effective Date
Employer
Employer's Requirements
Final Acceptance
Force Majeure Event
Good Industry Practice
Governmental Authority
Guarantee Test
Intellectual Property Rights
Interface Points
Key Personnel
Liquidated Damages
Milestone
Notice to Proceed
Performance Guarantee
Performance Security
Performance Tests
Project
Project Schedule
Provisional Acceptance
Punch List
Quality Assurance Plan
Site
Specifications
Subcontractor
Substantial Completion
Taking Over
Technical Documents
Technology License
Time for Completion
Variation
Warranty Period
Work
Working Day
Clauses
Interpretation
Contract Formation
Scope of Work
Design Obligations
Construction Obligations
Testing and Commissioning
Quality Assurance
Project Schedule
Payment Terms
Performance Security
Insurance
Force Majeure
Variations
Warranties
Defects Liability
Intellectual Property
Confidentiality
Health and Safety
Environmental Compliance
Labor and Employment
Subcontracting
Assignment and Novation
Dispute Resolution
Governing Law
Termination
Indemnification
Site Access and Conditions
Materials and Equipment
Documentation and Reporting
Permits and Approvals
Risk Allocation
Performance Guarantees
Interface Management
Acceptance Criteria
Training and Knowledge Transfer
Spare Parts and Maintenance
Liquidated Damages
Limitation of Liability
Title and Risk
Suspension
Representations and Warranties
Contract Formation
Scope of Work
Design Obligations
Construction Obligations
Testing and Commissioning
Quality Assurance
Project Schedule
Payment Terms
Performance Security
Insurance
Force Majeure
Variations
Warranties
Defects Liability
Intellectual Property
Confidentiality
Health and Safety
Environmental Compliance
Labor and Employment
Subcontracting
Assignment and Novation
Dispute Resolution
Governing Law
Termination
Indemnification
Site Access and Conditions
Materials and Equipment
Documentation and Reporting
Permits and Approvals
Risk Allocation
Performance Guarantees
Interface Management
Acceptance Criteria
Training and Knowledge Transfer
Spare Parts and Maintenance
Liquidated Damages
Limitation of Liability
Title and Risk
Suspension
Representations and Warranties
Relevant Industries
Infrastructure Development
Industrial Manufacturing
Power Generation
Oil and Gas
Chemical Processing
Pharmaceutical Manufacturing
Real Estate Development
Transportation
Renewable Energy
Water Treatment
Mining
Healthcare Facilities
Data Centers
Aerospace and Defense
Automotive Manufacturing
Relevant Teams
Legal
Project Management
Operations
Finance
Procurement
Engineering
Construction
Quality Assurance
Health Safety Environment
Risk Management
Commercial
Business Development
Technical Services
Contract Administration
Relevant Roles
Project Director
Chief Executive Officer
Chief Operating Officer
Contract Manager
Project Manager
Legal Counsel
Chief Financial Officer
Procurement Manager
Technical Director
Construction Manager
Risk Manager
Commercial Director
Operations Director
Engineering Manager
Quality Assurance Manager
HSE Manager
Cost Controller
Business Development Director
Find the exact document you need
Lien Contract
An Indian law-governed agreement establishing a lien right over specified property as security for an underlying obligation.
find out more
Labour Contract Form
A standardized employment agreement compliant with Indian labor laws, establishing terms and conditions of employment between employer and employee.
find out more
House Wiring Contract
An Indian law-governed contract for electrical wiring installation services, specifying technical requirements, safety standards, and compliance with Indian electrical regulations.
find out more
Handyman Maintenance Contract
An Indian law-governed agreement between a handyman/maintenance service provider and property owner/manager, outlining maintenance services, terms, and obligations.
find out more
General Contract
A versatile contract template under Indian law that establishes formal business relationships between parties, compliant with the Indian Contract Act and related legislation.
find out more
Contractor Non Compete Agreement
An Indian law-compliant agreement restricting a contractor's competitive activities during their engagement period, protecting company interests while maintaining enforceability under Section 27 of the Indian Contract Act.
find out more
Contractor Lien Release
An Indian legal document where a contractor waives their right to place a lien on a property after receiving payment for work performed or materials supplied.
find out more
Contract With Builder
An Indian law-governed agreement between property owner and builder for construction works, compliant with RERA and construction regulations.
find out more
Contractors Agreement Form
An Indian law-governed agreement establishing terms and conditions between a hiring entity and a contractor, defining their professional relationship and mutual obligations.
find out more
Conditions Of Contract For (Construction)
Standard construction contract conditions template under Indian law governing rights, obligations, and procedures for construction projects in India.
find out more
Construction Agreement Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction works, including scope, payments, and compliance requirements.
find out more
Basic Independent Contractor Agreement
An Indian law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining service scope, payment terms, and contractor status.
find out more
Architect Contract Agreement
An Indian law-governed agreement between an architect/architectural firm and client, defining architectural services, fees, and mutual obligations.
find out more
Simple Contract Labor Agreement
An Indian law-compliant agreement between a Principal Employer and Contractor for the provision and management of contract labor services.
find out more
Private Security Contract
An Indian law-governed agreement for private security services provision, compliant with PSARA 2005 and related regulations.
find out more
Payment Contract Agreement
An Indian law-governed agreement establishing payment terms, schedules, and obligations between parties, ensuring compliant and secure monetary transactions.
find out more
Contractor Work Contract
An India-compliant Contractor Work Contract establishing terms and conditions for independent contractor services, including scope, payment, and deliverables.
find out more
Building Construction Labour Contract Agreement
An Indian jurisdiction labor contract agreement for construction projects, establishing terms between principal employers and labor contractors while ensuring compliance with local construction and labor laws.
find out more
Developer Contractor Agreement
An Indian law-governed agreement establishing terms for engaging an independent developer contractor, including service scope, payments, and IP rights.
find out more
Standard Form Of Agreement Between Owner And Contractor
An Indian law-governed agreement between property owner and contractor defining construction project terms, obligations, and deliverables.
find out more
Turnkey Contract
An Indian law-governed contract for the complete design, construction, and delivery of a fully operational facility, where the contractor assumes total responsibility from design through commissioning.
find out more
Time And Materials Contract
An Indian law-governed agreement for charging based on actual time spent and materials used in project delivery, including rates, tracking, and approval processes.
find out more
Standard Renovation Contract
An Indian law-governed contract establishing terms and conditions for property renovation works between owners and contractors.
find out more
Swimming Pool Contract
An Indian law-governed contract for swimming pool construction and installation, detailing specifications, responsibilities, and compliance requirements.
find out more
Suppliers Contract Agreement
An Indian law-governed agreement establishing terms and conditions between a purchaser and supplier for the provision of goods or services.
find out more
Service Contract Proposal
An Indian law-compliant Service Contract Proposal template outlining service arrangements, terms, and obligations between parties under Indian jurisdiction.
find out more
Residential Solar Installation Contract
An Indian law-governed contract for residential solar power system installation, covering technical specifications, warranties, and regulatory compliance.
find out more
Restoration Contract
An Indian law-governed contract specifying terms and conditions for property restoration work, including scope, specifications, timelines, and compliance requirements.
find out more
Receipt Contract
A legally binding document under Indian law that provides formal evidence of a financial transaction or transfer of goods/services, compliant with Indian Contract Act and GST regulations.
find out more
Real Estate Contractor Agreement
An Indian law-governed agreement between property owner/developer and contractor establishing terms and conditions for construction services, including scope, payments, and compliance requirements.
find out more
Proposal And Contract
An Indian law-governed document combining a business proposal with binding contractual terms, establishing commercial and legal parameters for business relationships.
find out more
Owner's Representative Contract
An Indian law-governed agreement appointing a representative to act on behalf of a property owner, defining their authority, responsibilities, and compensation.
find out more
Masonry Contract
An Indian law-governed contract establishing terms and conditions for masonry construction work, including quality standards, specifications, and compliance requirements.
find out more
Marketing Agreement Contract
An Indian law-governed agreement establishing terms between a marketing service provider and client for marketing services delivery, including scope, payments, and compliance requirements.
find out more
Lump Sum Contract
An Indian law-governed fixed-price contract establishing terms for project delivery at a predetermined lump sum amount, with defined scope and milestone-based payments.
find out more
Insurance Agency Agreement
An Indian law-governed agreement establishing the relationship between an insurance company and its agent, compliant with IRDAI regulations.
find out more
Labour Only Subcontractor Agreement
Indian law-compliant agreement template for engaging labor-only subcontractors, ensuring compliance with local labor regulations and statutory requirements.
find out more
Kitchen Renovation Contract
An Indian law-governed contract for kitchen renovation projects, defining scope, terms, and obligations between contractors and property owners.
find out more
Kitchen Contract
An Indian law-governed agreement for kitchen construction or renovation services, outlining project specifications, terms, and obligations of all parties involved.
find out more
Labour Supply Contract
An Indian law-governed agreement between a labor contractor and principal employer for the supply and management of contract workers.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)