A Works Contract is essential for any construction or engineering project in England and Wales where one party (the contractor) agrees to carry out construction works for another (the employer). This contract type is fundamental to ensuring clear understanding of project scope, payment mechanisms, timelines, and quality standards. It incorporates mandatory provisions required by UK construction legislation, including payment terms and dispute resolution procedures. The Works Contract serves as the primary document governing the relationship between parties and should be carefully drafted to reflect specific project requirements and risk allocation.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
Works Contract
"I need a Works Contract for a commercial office building renovation project in Manchester, with a contract value of £2.5 million and completion date of March 2025, including specific provisions for sustainable materials and phased completion."
1. Parties: Identification and details of contracting parties
2. Background: Context and purpose of the works contract
3. Definitions: Key terms used throughout the contract
4. Scope of Works: Detailed description of works to be performed
5. Contract Price and Payment Terms: Payment amounts, mechanisms, and schedules including requirements under Housing Grants, Construction and Regeneration Act 1996
6. Programme of Works: Timeline and completion dates
7. Contractor Obligations: Key responsibilities of the contractor including quality standards under Supply of Goods and Services Act 1982
8. Employer Obligations: Key responsibilities of the employer
9. Health and Safety: Requirements under CDM Regulations 2015 and health and safety legislation
10. Variations: Process for managing changes to scope
11. Defects and Warranties: Defect identification, rectification periods and warranty provisions
12. Insurance and Liability: Insurance requirements and liability limitations
13. Termination: Grounds and process for contract termination
14. Dispute Resolution: Procedures for resolving disputes including statutory adjudication rights
1. Design Obligations: Required when contractor has design responsibilities in design and build contracts
2. Performance Bond: Security for performance, typically used in high-value contracts
3. Parent Company Guarantee: Additional security from contractor's parent company when working with subsidiary companies
4. Intellectual Property Rights: Required when design or creative works are involved
5. Collateral Warranties: Required when third-party rights need to be established
1. Schedule of Works: Detailed breakdown of works to be performed
2. Schedule of Rates: Pricing breakdown and rates for various works elements
3. Programme: Detailed timeline of works
4. Site Information: Details about the construction site and conditions
5. Drawings and Specifications: Technical drawings and specifications for the works
6. Insurance Requirements: Details of required insurance coverage
7. Key Personnel: List of key personnel and their responsibilities
8. Form of Warranties: Template warranties to be provided
Authors
Relevant legal definitions
Agreement
Applicable Laws
Base Date
CDM Regulations
Commencement Date
Completion Date
Construction Documents
Contract Price
Contract Sum
Contractor
Contractor's Equipment
Defects
Defects Liability Period
Delaying Events
Design Documents
Employer
Employer's Requirements
Extension of Time
Final Certificate
Force Majeure
Good Industry Practice
Intellectual Property Rights
Interim Payment
Loss and Expense
Materials
Payment Due Date
Practical Completion
Programme
Project
Project Manager
Retention
Site
Specifications
Subcontractor
Supervising Officer
Time for Completion
Variations
Works
Working Day
Applicable Laws
Base Date
CDM Regulations
Commencement Date
Completion Date
Construction Documents
Contract Price
Contract Sum
Contractor
Contractor's Equipment
Defects
Defects Liability Period
Delaying Events
Design Documents
Employer
Employer's Requirements
Extension of Time
Final Certificate
Force Majeure
Good Industry Practice
Intellectual Property Rights
Interim Payment
Loss and Expense
Materials
Payment Due Date
Practical Completion
Programme
Project
Project Manager
Retention
Site
Specifications
Subcontractor
Supervising Officer
Time for Completion
Variations
Works
Working Day
Clauses
Interpretation
Contractor's Obligations
Employer's Obligations
Programme of Works
Access to Site
Quality and Standards
Materials and Workmanship
Design Responsibilities
Variations
Extensions of Time
Payment
Retention
Insurance
Indemnities
Health and Safety
CDM Regulations
Force Majeure
Suspension
Termination
Defects Liability
Assignment and Subcontracting
Intellectual Property Rights
Confidentiality
Dispute Resolution
Performance Security
Warranties
Notices
Site Conditions
Practical Completion
Testing and Commissioning
Risk and Title
Liability Limitations
Governing Law and Jurisdiction
Entire Agreement
Contractor's Obligations
Employer's Obligations
Programme of Works
Access to Site
Quality and Standards
Materials and Workmanship
Design Responsibilities
Variations
Extensions of Time
Payment
Retention
Insurance
Indemnities
Health and Safety
CDM Regulations
Force Majeure
Suspension
Termination
Defects Liability
Assignment and Subcontracting
Intellectual Property Rights
Confidentiality
Dispute Resolution
Performance Security
Warranties
Notices
Site Conditions
Practical Completion
Testing and Commissioning
Risk and Title
Liability Limitations
Governing Law and Jurisdiction
Entire Agreement
Relevant Industries
Relevant Teams
Relevant Roles
Find the exact document you need
Rental Lease
An England & Wales legal document outlining landlord-tenant rights and obligations for residential property leases.
find out more
Cleaning Contract
A legal contract in England & Wales outlining terms for the sale and transfer of property ownership.
find out more
Specialty Contract
A formal legal instrument executed as a deed under English and Welsh law, providing enhanced enforceability and a 12-year limitation period.
find out more
Electrical Contract
A legally binding agreement for electrical works, governed by English and Welsh law, establishing terms between contractor and client.
find out more
Delivery Contract
A legally binding agreement under English and Welsh law establishing terms and conditions for delivery services between parties.
find out more
Landscaping Contract
An English law contract governing the provision of professional landscaping services.
find out more
Works Contract
A legally binding agreement under English law governing construction works, defining scope, terms, and party obligations.
find out more
Plumbing Contract
A contract for plumbing services under English and Welsh law, establishing terms between contractor and client.
find out more
Maintenance Contract
A legally binding agreement under English and Welsh law that establishes terms for maintenance services provision and performance standards.
find out more
HVAC Maintenance Contract
An England and Wales law-governed agreement establishing terms for HVAC system maintenance services.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our Trust Centre for more details and real-time security updates.
Read our Privacy Policy.
