The General Contractor Building Contract is a fundamental document in South African construction law that governs the relationship between property owners/developers and construction contractors. This agreement is essential for any significant construction project in South Africa, whether commercial, residential, or industrial. It incorporates requirements from key legislation including the National Building Regulations and Building Standards Act, Construction Industry Development Board Act, and Occupational Health and Safety Act. The contract typically includes detailed provisions for scope of works, payment terms, project timelines, quality standards, variations, and dispute resolution mechanisms. It's designed to protect both parties' interests while ensuring compliance with South African construction industry regulations and standards. The document is particularly crucial for projects where a general contractor takes primary responsibility for construction execution, whether working directly or through subcontractors.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
General Contractor Building Contract
"I need a General Contractor Building Contract for a large-scale commercial development project in Cape Town, South Africa, with a project value of R50 million and an expected completion date of March 2025, including specific provisions for green building requirements and local content obligations."
1. Parties: Identification and details of the Employer (Client) and the Contractor, including their registered addresses and registration numbers
2. Background: Context of the agreement, including the project overview and the parties' intentions
3. Definitions and Interpretation: Detailed definitions of terms used throughout the contract and rules for interpreting the agreement
4. Scope of Works: Detailed description of the construction work to be performed, including specifications and standards
5. Contract Price and Payment Terms: Amount payable, payment schedule, retention amounts, and payment certification process
6. Duration and Programme: Project timeline, completion dates, and programming requirements
7. Contractor's Obligations: Core responsibilities including workmanship, materials, supervision, and compliance with regulations
8. Employer's Obligations: Client's responsibilities including site access, approvals, and information provision
9. Health and Safety: Safety requirements, compliance with OHS Act, and safety management procedures
10. Quality Control: Quality standards, inspection procedures, and remedial work requirements
11. Variations: Procedures for handling changes to the scope of work and their cost implications
12. Insurance and Indemnities: Required insurance coverage and indemnification provisions
13. Defects Liability: Defects liability period, remediation procedures, and warranties
14. Suspension and Termination: Grounds and procedures for suspending or terminating the contract
15. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration
16. General Provisions: Standard contractual clauses including notices, governing law, and entire agreement
1. Performance Security: Requirements for performance bonds or guarantees, used for high-value contracts
2. Environmental Management: Environmental protection requirements, needed for projects with significant environmental impact
3. Local Content Requirements: Provisions for local labor and materials, required for public sector projects
4. Design Obligations: Used when the contractor has design responsibilities in addition to construction
5. Provisional Sums: Handling of provisional sum items, needed when certain costs cannot be determined at contract formation
6. Sectional Completion: Required when the project needs to be completed and handed over in sections
7. Subcontracting: Detailed subcontracting provisions, needed for projects with significant subcontracted work
8. Price Adjustment: Formula and procedures for price adjustments, needed for longer-term projects
1. Schedule 1: Contract Data: Key project information including contract price, completion date, and party details
2. Schedule 2: Scope of Works: Detailed specifications, drawings, and technical requirements
3. Schedule 3: Pricing Schedule: Detailed breakdown of prices, rates, and quantities
4. Schedule 4: Site Information: Site details, conditions, and access requirements
5. Schedule 5: Programme: Detailed construction programme and milestone dates
6. Schedule 6: Insurance Requirements: Specific insurance types and coverage amounts required
7. Appendix A: Drawing Register: List of all applicable drawings and revisions
8. Appendix B: Health and Safety Specifications: Detailed health and safety requirements and procedures
9. Appendix C: Quality Control Requirements: Quality management procedures and standards
10. Appendix D: Forms and Certificates: Standard forms for payment certificates, variations, and completion certificates
Authors
Relevant legal definitions
Agreement
Appendices
Architect
As-Built Drawings
Bill of Quantities
Certificate of Completion
Certificate of Practical Completion
Commencement Date
Construction Documents
Construction Period
Construction Programme
Contract
Contract Data
Contract Documents
Contract Price
Contract Works
Contractor
Day
Defects
Defects Liability Period
Drawings
Employer
Engineer
Extension of Time
Final Completion
Force Majeure
Governing Law
Health and Safety Plan
Interim Payment Certificate
Letter of Acceptance
Material
Nominated Subcontractor
Notice
Parties
Payment Certificate
Permanent Works
Practical Completion
Principal Agent
Programme of Works
Project
Project Manager
Provisional Sums
Quantity Surveyor
Regular Working Hours
Retention Money
Schedule of Rates
Site
Site Instructions
Specifications
Subcontractor
Substantial Completion
Temporary Works
Tender Documents
Time for Completion
Variation
Variation Order
Works
Working Day
Appendices
Architect
As-Built Drawings
Bill of Quantities
Certificate of Completion
Certificate of Practical Completion
Commencement Date
Construction Documents
Construction Period
Construction Programme
Contract
Contract Data
Contract Documents
Contract Price
Contract Works
Contractor
Day
Defects
Defects Liability Period
Drawings
Employer
Engineer
Extension of Time
Final Completion
Force Majeure
Governing Law
Health and Safety Plan
Interim Payment Certificate
Letter of Acceptance
Material
Nominated Subcontractor
Notice
Parties
Payment Certificate
Permanent Works
Practical Completion
Principal Agent
Programme of Works
Project
Project Manager
Provisional Sums
Quantity Surveyor
Regular Working Hours
Retention Money
Schedule of Rates
Site
Site Instructions
Specifications
Subcontractor
Substantial Completion
Temporary Works
Tender Documents
Time for Completion
Variation
Variation Order
Works
Working Day
Clauses
Parties
Definitions
Interpretation
Scope of Works
Contract Price
Payment Terms
Duration
Programme of Works
Site Access
Materials and Workmanship
Quality Control
Health and Safety
Environmental Protection
Insurance
Performance Security
Variations
Extensions of Time
Force Majeure
Suspension
Termination
Defects Liability
Warranties
Indemnification
Dispute Resolution
Confidentiality
Intellectual Property
Assignment and Subcontracting
Compliance with Laws
Notices
Risk Allocation
Site Conditions
Documentation
Testing and Inspection
Practical Completion
Final Completion
Retention
Bonds and Guarantees
Labor Requirements
Equipment and Plant
Project Management
Reporting Requirements
Claims Procedure
Limitation of Liability
Governing Law
Jurisdiction
Entire Agreement
Amendment
Severability
Waiver
Force Majeure
Boilerplate Clauses
Definitions
Interpretation
Scope of Works
Contract Price
Payment Terms
Duration
Programme of Works
Site Access
Materials and Workmanship
Quality Control
Health and Safety
Environmental Protection
Insurance
Performance Security
Variations
Extensions of Time
Force Majeure
Suspension
Termination
Defects Liability
Warranties
Indemnification
Dispute Resolution
Confidentiality
Intellectual Property
Assignment and Subcontracting
Compliance with Laws
Notices
Risk Allocation
Site Conditions
Documentation
Testing and Inspection
Practical Completion
Final Completion
Retention
Bonds and Guarantees
Labor Requirements
Equipment and Plant
Project Management
Reporting Requirements
Claims Procedure
Limitation of Liability
Governing Law
Jurisdiction
Entire Agreement
Amendment
Severability
Waiver
Force Majeure
Boilerplate Clauses
Relevant Industries
Construction
Real Estate Development
Infrastructure Development
Commercial Property
Residential Property
Industrial Development
Public Works
Mining Infrastructure
Healthcare Facilities
Educational Facilities
Retail Development
Hospitality
Relevant Teams
Legal
Construction
Operations
Commercial
Procurement
Risk and Compliance
Project Management
Technical
Business Development
Property Development
Relevant Roles
Construction Manager
Project Manager
Contract Manager
Legal Counsel
Quantity Surveyor
Site Manager
Commercial Director
Operations Director
Risk Manager
Compliance Officer
Procurement Manager
Chief Operating Officer
Development Manager
Technical Director
Construction Director
Find the exact document you need
House Contractor Agreement
An Indonesian law-governed agreement between property owner and contractor for residential construction projects, outlining construction terms, payments, and responsibilities.
find out more
Builder And Owner Agreement
A Saudi Arabian law-governed agreement between property owners and builders defining construction project terms, conditions, and obligations.
find out more
Service Level Agreement (Construction)
Construction Service Level Agreement template for Philippine jurisdiction, defining performance metrics and quality standards for construction projects.
find out more
Professional Services Agreement (Construction)
A Philippine law-governed agreement for professional services in construction projects, defining service scope, terms, and regulatory compliance requirements.
find out more
Preconstruction Agreement
A Philippine law-governed agreement defining terms and conditions for preconstruction services, including design review, cost estimation, and project planning activities.
find out more
General Contractor Building Contract
A South African law-governed contract between an employer and general contractor establishing terms and conditions for construction project execution.
find out more
Construction Management Agency Contract
A South African construction contract establishing an agency relationship between a Principal and Construction Manager for professional project management services.
find out more
Sub Contracting Agreement
A Maltese law-governed agreement between a main contractor and subcontractor defining delegated work scope, terms, and obligations.
find out more
Civil Contractor Agreement
A Maltese law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring regulatory compliance and clear business relationship parameters.
find out more
Construction Management Services Contract
A Pakistani law-governed agreement establishing terms and conditions for professional construction management services, including scope, responsibilities, and compliance requirements.
find out more
Contractor Subcontractor Contract Agreement
Austrian law-governed agreement between a main contractor and subcontractor for the provision of specified works or services, compliant with Austrian legal requirements.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our Trust Centre for more details and real-time security updates.
Read our Privacy Policy.