The Construction Management Services Contract is essential for projects requiring professional construction management oversight in Pakistan. This agreement is typically used when a project owner needs specialized expertise to manage complex construction projects, ensuring efficient project delivery while maintaining quality and compliance standards. The contract comprehensively covers the construction manager's scope of services, from pre-construction planning through project completion, including budget management, schedule control, quality assurance, and stakeholder coordination. It incorporates requirements from Pakistani legislation, including the Contract Act 1872, Pakistan Engineering Council regulations, and provincial building codes, while addressing specific project needs and risk allocation. The document is crucial for establishing clear lines of authority, responsibilities, and accountability in construction projects, particularly important in Pakistan's developing infrastructure and real estate sectors.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
Construction Management Services Contract
"I need a Construction Management Services Contract for a large-scale commercial development project in Lahore, Pakistan, with specific provisions for phased construction starting March 2025 and enhanced safety requirements due to the site's location in a busy urban area."
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
1. Parties: Identification of the Client and Construction Manager, including full legal names, addresses, and registration details
2. Background: Context of the agreement, project overview, and purpose of engaging the construction management services
3. Definitions: Detailed definitions of technical terms, project-specific terminology, and contract-specific references
4. Scope of Services: Comprehensive description of construction management services to be provided, including pre-construction, construction, and post-construction phases
5. Construction Manager's Obligations: Detailed responsibilities including project supervision, quality control, schedule management, and coordination with stakeholders
6. Client's Obligations: Client's responsibilities including provision of information, approvals, site access, and payment obligations
7. Project Timeline: Project schedule, milestones, and completion dates
8. Fees and Payment Terms: Construction management fee structure, payment schedule, and related financial terms
9. Personnel and Resources: Key personnel requirements, staffing obligations, and resource commitments
10. Quality Standards: Quality assurance requirements and applicable construction standards
11. Reporting and Documentation: Requirements for project reports, documentation, and communication protocols
12. Insurance and Liability: Insurance requirements, indemnification provisions, and limitation of liability
13. Termination: Conditions and procedures for contract termination by either party
14. Dispute Resolution: Procedures for handling disputes, including mediation and arbitration processes
15. Governing Law: Specification of Pakistani law as governing law and relevant jurisdiction
1. Force Majeure: Provisions for unforeseen circumstances preventing contract performance, particularly relevant in areas with political or environmental instability
2. Intellectual Property Rights: Required when the services include design work or proprietary management systems
3. Environmental Compliance: Detailed environmental obligations when project has significant environmental impact
4. Safety Management: Enhanced safety provisions for high-risk construction projects
5. Subcontracting: Terms for engaging and managing subcontractors, if permitted
6. Technology and Software: When specific construction management software or technology platforms are to be used
7. Local Content Requirements: For projects subject to local content or employment requirements
8. Security Requirements: For projects in sensitive locations or with specific security needs
9. Performance Bonds: When additional financial security is required
10. Warranty Period Services: For extended service requirements post-completion
1. Schedule A - Scope of Services Detail: Detailed breakdown of construction management services and deliverables
2. Schedule B - Fee Schedule: Detailed fee structure, rates, and payment milestones
3. Schedule C - Project Program: Detailed project timeline, milestones, and critical path activities
4. Schedule D - Key Personnel: CVs and responsibilities of key team members
5. Schedule E - Required Reports and Documentation: Templates and requirements for project reporting
6. Schedule F - Quality Management Plan: Detailed quality assurance and control procedures
7. Schedule G - Site Information: Site details, access requirements, and existing conditions
8. Schedule H - Client's Requirements: Detailed technical and operational requirements from the client
9. Appendix 1 - Insurance Requirements: Detailed insurance coverage requirements and minimum limits
10. Appendix 2 - Health and Safety Requirements: Specific health and safety procedures and requirements
11. Appendix 3 - Forms and Templates: Standard forms for project administration and reporting
Authors
Relevant legal definitions
Agreement
Applicable Laws
Approval
As-Built Drawings
Authority
Bill of Quantities
Change Order
Client
Client's Representative
Commencement Date
Completion Certificate
Confidential Information
Construction Documents
Construction Manager
Construction Period
Construction Schedule
Contract Price
Contractor
Defects Liability Period
Deliverables
Design Documents
Dispute
Extension of Time
Force Majeure Event
Good Industry Practice
Governing Law
Intellectual Property Rights
Key Personnel
Material Breach
Milestone
Notice
Payment Certificate
Performance Standards
Project
Project Site
Quality Assurance Plan
Relevant Authority
Schedule of Rates
Scope of Services
Services
Site Conditions
Specifications
Subcontractor
Substantial Completion
Technical Requirements
Term
Time for Completion
Variation
Works
Applicable Laws
Approval
As-Built Drawings
Authority
Bill of Quantities
Change Order
Client
Client's Representative
Commencement Date
Completion Certificate
Confidential Information
Construction Documents
Construction Manager
Construction Period
Construction Schedule
Contract Price
Contractor
Defects Liability Period
Deliverables
Design Documents
Dispute
Extension of Time
Force Majeure Event
Good Industry Practice
Governing Law
Intellectual Property Rights
Key Personnel
Material Breach
Milestone
Notice
Payment Certificate
Performance Standards
Project
Project Site
Quality Assurance Plan
Relevant Authority
Schedule of Rates
Scope of Services
Services
Site Conditions
Specifications
Subcontractor
Substantial Completion
Technical Requirements
Term
Time for Completion
Variation
Works
Clauses
Appointment
Services Scope
Duration
Project Schedule
Construction Manager's Obligations
Client's Obligations
Personnel Requirements
Fees and Payment
Performance Standards
Quality Control
Health and Safety
Environmental Compliance
Reporting Requirements
Document Management
Variations
Insurance
Indemnification
Liability Limitation
Force Majeure
Confidentiality
Intellectual Property
Termination
Suspension
Assignment and Subcontracting
Dispute Resolution
Notices
Governing Law
Site Access
Warranty
Performance Security
Risk Allocation
Compliance with Laws
Records and Audits
Project Coordination
Change Management
Services Scope
Duration
Project Schedule
Construction Manager's Obligations
Client's Obligations
Personnel Requirements
Fees and Payment
Performance Standards
Quality Control
Health and Safety
Environmental Compliance
Reporting Requirements
Document Management
Variations
Insurance
Indemnification
Liability Limitation
Force Majeure
Confidentiality
Intellectual Property
Termination
Suspension
Assignment and Subcontracting
Dispute Resolution
Notices
Governing Law
Site Access
Warranty
Performance Security
Risk Allocation
Compliance with Laws
Records and Audits
Project Coordination
Change Management
Relevant Industries
Real Estate Development
Infrastructure
Commercial Construction
Industrial Development
Healthcare Facilities
Education Facilities
Hospitality
Retail Development
Energy Infrastructure
Transportation Infrastructure
Public Works
Manufacturing Facilities
Mixed-use Development
Residential Development
Relevant Teams
Legal
Construction
Operations
Commercial
Procurement
Risk Management
Project Management
Technical Services
Quality Assurance
Compliance
Business Development
Finance
Engineering
Relevant Roles
Construction Manager
Project Director
Contract Manager
Commercial Director
Legal Counsel
Project Manager
Construction Director
Operations Manager
Risk Manager
Procurement Manager
Technical Director
Chief Engineer
Development Manager
Compliance Officer
Quality Assurance Manager
Find the exact document you need
House Contractor Agreement
An Indonesian law-governed agreement between property owner and contractor for residential construction projects, outlining construction terms, payments, and responsibilities.
find out more
Builder And Owner Agreement
A Saudi Arabian law-governed agreement between property owners and builders defining construction project terms, conditions, and obligations.
find out more
Service Level Agreement (Construction)
Construction Service Level Agreement template for Philippine jurisdiction, defining performance metrics and quality standards for construction projects.
find out more
Professional Services Agreement (Construction)
A Philippine law-governed agreement for professional services in construction projects, defining service scope, terms, and regulatory compliance requirements.
find out more
Preconstruction Agreement
A Philippine law-governed agreement defining terms and conditions for preconstruction services, including design review, cost estimation, and project planning activities.
find out more
General Contractor Building Contract
A South African law-governed contract between an employer and general contractor establishing terms and conditions for construction project execution.
find out more
Construction Management Agency Contract
A South African construction contract establishing an agency relationship between a Principal and Construction Manager for professional project management services.
find out more
Sub Contracting Agreement
A Maltese law-governed agreement between a main contractor and subcontractor defining delegated work scope, terms, and obligations.
find out more
Civil Contractor Agreement
A Maltese law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring regulatory compliance and clear business relationship parameters.
find out more
Construction Management Services Contract
A Pakistani law-governed agreement establishing terms and conditions for professional construction management services, including scope, responsibilities, and compliance requirements.
find out more
Contractor Subcontractor Contract Agreement
Austrian law-governed agreement between a main contractor and subcontractor for the provision of specified works or services, compliant with Austrian legal requirements.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our Trust Centre for more details and real-time security updates.
Read our Privacy Policy.