1. Parties: Identifies and provides full details of the Client and Contractor, including registration numbers, addresses, and authorized representatives
2. Background: Outlines the context of the agreement, including the Client's ownership of the site and intention to construct, and the Contractor's expertise and qualifications
3. Definitions: Defines key terms used throughout the agreement to ensure clarity and prevent misinterpretation
4. Scope of Work: Detailed description of the construction works to be performed by the Contractor, including general obligations and exclusions
5. Contract Price and Payment Terms: Specifies the total contract value, payment schedule, method of payment, and conditions for payment
6. Timeline and Completion: Sets out the project schedule, completion date, mechanisms for extensions of time, and consequences of delay
7. Contractor's Obligations: Comprehensive list of Contractor's responsibilities including quality standards, safety measures, and compliance requirements
8. Client's Obligations: Specifies Client's responsibilities including site access, approvals, and provision of necessary information
9. Materials and Workmanship: Standards for materials, testing requirements, and quality control procedures
10. Variations: Procedures for handling changes to scope, pricing of variations, and approval process
11. Insurance and Indemnity: Required insurance coverage and indemnification obligations of both parties
12. Defects Liability: Duration and scope of defects liability period, remediation process, and warranties
13. Termination: Grounds for termination, termination process, and consequences of termination
14. Dispute Resolution: Methods and procedures for resolving disputes, including mediation and arbitration processes
15. Force Majeure: Definition of force majeure events and their consequences on contractual obligations
16. Governing Law and Jurisdiction: Specifies applicable law and jurisdiction for contract interpretation and disputes
