The Standard Form of Agreement Between Owner and Contractor serves as the primary contract document for construction projects in Nigeria, establishing the legal and commercial framework for project execution. This agreement is typically used when a project owner needs to engage a main contractor for construction works, whether for new builds, renovations, or infrastructure projects. It includes comprehensive provisions for project execution, payment mechanisms, quality control, and risk allocation, while ensuring compliance with Nigerian construction laws, environmental regulations, and local content requirements. The document is designed to be adaptable to various project sizes and types while maintaining consistency with Nigerian legal requirements and construction industry best practices. It provides essential protection for both parties' interests through clear delineation of responsibilities, robust dispute resolution mechanisms, and standard industry procedures for contract administration.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification and details of the Owner and Contractor, including registration numbers and addresses
2. Background: Context of the agreement, project overview, and basis for the contractual relationship
3. Definitions and Interpretation: Definitions of key terms used in the agreement and rules for interpreting the contract
4. Scope of Work: Detailed description of the work to be performed by the Contractor
5. Contract Price and Payment: Amount payable, payment schedule, payment terms, and invoicing requirements
6. Project Timeline: Commencement date, completion date, project milestones, and extension provisions
7. Contractor's Obligations: Key responsibilities and duties of the Contractor including quality standards
8. Owner's Obligations: Key responsibilities and duties of the Owner including site access and approvals
9. Materials and Workmanship: Standards for materials, quality requirements, and workmanship specifications
10. Variations and Changes: Process for handling changes to scope, pricing, or timeline
11. Health and Safety: Safety requirements, protocols, and responsibilities
12. Insurance and Indemnity: Required insurance coverage and indemnification obligations
13. Defects Liability: Defects notification period, remediation process, and warranties
14. Suspension and Termination: Grounds and process for suspension or termination of the contract
15. Dispute Resolution: Process for resolving disputes including mediation and arbitration
16. General Provisions: Standard contractual provisions including notices, governing law, and assignment
1. Performance Security: Requirements for performance bonds or guarantees, used for high-value projects
2. Local Content Requirements: Specific provisions for local content compliance, required for oil/gas sector projects
3. Environmental Management: Detailed environmental requirements, needed for environmentally sensitive projects
4. Advance Payment: Terms for advance payments and associated guarantees, used when advance funding is required
5. Force Majeure: Provisions for unforeseen circumstances, recommended for long-term projects
6. Intellectual Property: IP rights and obligations, needed for projects involving design or technology elements
7. Liquidated Damages: Pre-agreed damages for delays or performance failures, used for time-critical projects
8. Quality Management System: Detailed quality management requirements, for complex technical projects
9. Subcontracting: Rules and restrictions on subcontracting, for projects allowing subcontractors
1. Schedule 1 - Scope of Works: Detailed technical specifications and scope breakdown
2. Schedule 2 - Contract Price Breakdown: Detailed pricing, rates, and payment milestones
3. Schedule 3 - Project Timeline: Detailed program of works and milestone dates
4. Schedule 4 - Key Personnel: List of key personnel from both parties and their roles
5. Schedule 5 - Technical Specifications: Detailed technical requirements and standards
6. Schedule 6 - Site Information: Site details, access requirements, and existing conditions
7. Schedule 7 - Forms and Procedures: Standard forms for variations, payments, and certificates
8. Schedule 8 - Insurance Requirements: Detailed insurance specifications and coverage limits
9. Appendix A - Drawings: Project drawings and design documents
10. Appendix B - Permits and Approvals: Required permits and regulatory approvals
Relevant legal definitions
Agreement
Applicable Laws
Approval
Architect
As-Built Drawings
Bill of Quantities
Certificate of Completion
Change Order
Commencement Date
Completion Date
Construction Documents
Construction Equipment
Construction Period
Contract Documents
Contract Price
Contract Time
Contractor
Contractor's Equipment
Day
Defects Liability Period
Deliverables
Design Documents
Drawings
Engineer
Extension of Time
Final Completion
Force Majeure
Good Industry Practice
Governing Law
Health and Safety Plan
Interim Payment Certificate
Local Content Requirements
Materials
Milestone
Notice
Notice to Proceed
Owner
Owner's Representative
Payment Certificate
Performance Security
Permits
Project
Project Manager
Project Schedule
Quality Control Plan
Quantity Surveyor
Retention Money
Site
Specifications
Subcontractor
Substantial Completion
Variation
Work
Working Day
Works
Applicable Laws
Approval
Architect
As-Built Drawings
Bill of Quantities
Certificate of Completion
Change Order
Commencement Date
Completion Date
Construction Documents
Construction Equipment
Construction Period
Contract Documents
Contract Price
Contract Time
Contractor
Contractor's Equipment
Day
Defects Liability Period
Deliverables
Design Documents
Drawings
Engineer
Extension of Time
Final Completion
Force Majeure
Good Industry Practice
Governing Law
Health and Safety Plan
Interim Payment Certificate
Local Content Requirements
Materials
Milestone
Notice
Notice to Proceed
Owner
Owner's Representative
Payment Certificate
Performance Security
Permits
Project
Project Manager
Project Schedule
Quality Control Plan
Quantity Surveyor
Retention Money
Site
Specifications
Subcontractor
Substantial Completion
Variation
Work
Working Day
Works
Clauses
Definitions and Interpretation
Scope of Work
Contract Price
Payment Terms
Project Timeline
Contractor Obligations
Owner Obligations
Materials and Equipment
Quality Control
Health and Safety
Environmental Compliance
Local Content
Insurance
Indemnification
Performance Security
Variations
Force Majeure
Suspension
Termination
Dispute Resolution
Warranties
Defects Liability
Site Access
Subcontracting
Assignment
Confidentiality
Intellectual Property
Notices
Governing Law
Records and Audit
Compliance with Laws
Labor Requirements
Testing and Inspection
Completion and Handover
Liquidated Damages
Risk Allocation
Securities and Guarantees
Scope of Work
Contract Price
Payment Terms
Project Timeline
Contractor Obligations
Owner Obligations
Materials and Equipment
Quality Control
Health and Safety
Environmental Compliance
Local Content
Insurance
Indemnification
Performance Security
Variations
Force Majeure
Suspension
Termination
Dispute Resolution
Warranties
Defects Liability
Site Access
Subcontracting
Assignment
Confidentiality
Intellectual Property
Notices
Governing Law
Records and Audit
Compliance with Laws
Labor Requirements
Testing and Inspection
Completion and Handover
Liquidated Damages
Risk Allocation
Securities and Guarantees
Relevant Industries
Construction
Real Estate Development
Infrastructure
Oil and Gas
Manufacturing
Healthcare
Education
Hospitality
Commercial Development
Industrial Development
Residential Development
Transportation
Energy
Mining
Telecommunications
Relevant Teams
Legal
Commercial
Operations
Project Management
Construction
Procurement
Technical
Risk Management
Compliance
Health and Safety
Contract Administration
Quality Control
Development
Engineering
Finance
Relevant Roles
Project Director
Construction Manager
Contract Manager
Legal Counsel
Commercial Manager
Project Manager
Quantity Surveyor
Chief Engineer
Procurement Manager
Risk Manager
Operations Director
Technical Director
Development Manager
Site Manager
Cost Controller
Claims Manager
Compliance Officer
Health and Safety Manager
Find the exact document you need
Contractor Work Contract
A Nigerian law-governed agreement establishing terms and conditions between a company and independent contractor, defining work scope, compensation, and contractor status.
find out more
Contractor Deposit Agreement
A Nigerian law-governed agreement establishing terms for client deposits to contractors, including payment, protection, and release conditions.
find out more
Short Form Of Contract
A simplified contract template under Nigerian law for basic commercial arrangements and business transactions.
find out more
Building Construction Labour Contract Agreement
A Nigerian law-governed agreement establishing employment terms and conditions for construction workers, ensuring compliance with local labor and construction regulations.
find out more
Contract Between Company And Contractor
A Nigerian law-governed agreement establishing terms and conditions between a company and independent contractor, defining services, payments, and obligations.
find out more
Developer Contractor Agreement
A Nigerian law-governed agreement establishing terms and conditions between a company and an independent software developer contractor.
find out more
Home Contractor Contract
A Nigerian law-governed contract between a homeowner and contractor for residential construction or renovation work, outlining work scope, terms, and mutual obligations.
find out more
Standard Independent Contractor Contract
A Nigerian law-governed agreement establishing and regulating the relationship between a company and an independent contractor, defining services, terms, and obligations.
find out more
Independent Contractor Agreement For IT Services
A Nigerian law-governed agreement establishing terms and conditions between a client and an independent contractor for IT service provision, ensuring clear scope, deliverables, and compliance with local regulations.
find out more
Standard Form Of Agreement Between Owner And Contractor
A Nigerian law-governed construction agreement between owner and contractor establishing project terms, conditions, and responsibilities.
find out more
Employee Work Contract Agreement
A Nigerian law-governed employment agreement establishing terms and conditions between employer and employee.
find out more
Simple Construction Contract Agreement
A Nigerian law-governed construction agreement establishing key terms and obligations between contractor and client for building projects.
find out more
Contractor Payment Agreement
A Nigerian law-governed agreement that establishes payment terms and conditions between a company and a contractor, ensuring compliance with local tax and labor regulations.
find out more
Contractor Client Agreement
A Nigerian law-governed agreement establishing terms and conditions between a client and independent contractor for professional services.
find out more
Agreement Between Owner And Builder
A Nigerian law-governed agreement between property owner and builder defining construction project terms, responsibilities, and obligations.
find out more
Contractor Lease Agreement
A Nigerian law-governed agreement establishing terms for contractor property lease, including rights, obligations, and operational parameters.
find out more
Private Practice Independent Contractor Agreement
A Nigerian law-governed agreement establishing terms between a professional practice and an independent contractor, defining service terms while maintaining contractor independence.
find out more
Self Employed Agreement Contract
A Nigerian law-governed agreement establishing the terms and conditions between a business and a self-employed contractor.
find out more
Subcontractor To Subcontractor Agreement
A Nigerian law-governed agreement between two subcontractors for the delegation of contracted work from one subcontractor to another.
find out more
Generic Contractor Agreement
A Nigerian law-governed contractor agreement template establishing independent contractor relationships with comprehensive terms and conditions.
find out more
Residential Building Contract Agreement
A Nigerian law-governed contract between property owner and contractor for residential construction projects, outlining construction terms, standards, and obligations.
find out more
Independent Service Contract
A Nigerian law-governed agreement establishing terms and conditions between a client and independent contractor for provision of specific services.
find out more
Home Improvement Agreement
A Nigerian-law governed agreement for home improvement projects, establishing terms between homeowners and contractors with local regulatory compliance.
find out more
Freelance Contractor Agreement
A Nigerian law-governed agreement establishing terms and conditions between a client and freelance contractor, defining services, payments, and independent contractor status.
find out more
Sole Trader Contract
A legally compliant Sole Trader Contract for business relationships in Nigeria, aligned with Nigerian business and contract law.
find out more
Simple Payment Agreement Contract
A Nigerian law-governed agreement establishing payment terms and obligations between parties, with detailed payment schedules and enforcement provisions.
find out more
Labour Hire Contract
A Nigerian law-governed agreement for temporary worker provision through labour hire arrangements, establishing rights and obligations between labour hire companies, host employers, and workers.
find out more
Contractor Service Agreement
A Nigerian law-governed agreement establishing terms and conditions between a client and independent contractor for provision of specific services.
find out more
Contract For Labor Agreement
A Nigerian law-compliant employment contract establishing terms and conditions between employer and employee, incorporating local labor law requirements.
find out more
Consulting Agreement Contract
A Nigerian law-governed agreement establishing terms and conditions between a consultant and client for professional consulting services.
find out more
Civil Work Contract Agreement
A Nigerian law-governed agreement for civil construction works, establishing terms between employer and contractor.
find out more
Standard Builders Contract
A Nigerian law-governed construction agreement establishing terms and conditions for building projects between employers and contractors.
find out more
Short Contractor Agreement
A streamlined contractor agreement under Nigerian law establishing independent service provider relationships while protecting both parties' interests.
find out more
Simple Contractor Contract
A straightforward contractor agreement under Nigerian law establishing independent contractor relationships and essential terms of engagement.
find out more
Salon Contract For Employees
A Nigerian-law compliant employment contract for salon staff, establishing terms and conditions for salon work while ensuring regulatory compliance.
find out more
Real Estate Construction Contract
A Nigerian law-governed agreement setting out terms and conditions for real estate construction works, defining rights and obligations of property owners and contractors.
find out more
Percentage Agreement Contract
A Nigerian law-governed agreement establishing percentage-based financial arrangements between parties, including calculation methods and payment terms.
find out more
Mining Contractor Agreement
A Nigerian law-governed agreement between a mining company and contractor for the provision of mining services, incorporating local regulatory requirements and industry standards.
find out more
Janitorial Subcontractor Agreement
A Nigerian law-governed agreement between a main contractor and janitorial subcontractor for the provision of cleaning services, including terms, conditions, and compliance requirements.
find out more
Independent Employment Agreement
A Nigerian law-governed agreement establishing an independent contractor relationship between a company and a service provider, defining services, terms, and mutual obligations.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)