Construction Agreement Between Owner And Contractor for Singapore

Construction Agreement Between Owner And Contractor Template for Singapore

A comprehensive legal agreement governed by Singapore law that establishes the contractual relationship between a property owner and a construction contractor. The agreement details the scope of work, payment terms, timelines, and obligations of both parties while ensuring compliance with Singapore's Building Control Act, SOPA, and related construction regulations. It includes provisions for dispute resolution, insurance requirements, and quality standards specific to Singapore's construction industry.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Generate a Bespoke Document

1. Select your governing law:

2. Enter your key requirements:

3. Create your document to edit, review or download

Download a Standard Template

Get our Singapore-compliant Construction Agreement Between Owner And Contractor

4.6 / 5

4.8 / 5

Alternatively: Run an advanced review of an existing
Construction Agreement Between Owner And Contractor

Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

Upload your Doc

What is a Construction Agreement Between Owner And Contractor?

The Construction Agreement Between Owner And Contractor is a fundamental document in Singapore's construction industry, essential for any building project regardless of scale. It provides legal protection for both parties while ensuring compliance with Singapore's strict building regulations and industry standards. This agreement is particularly important given Singapore's comprehensive construction laws, including the Building Control Act and Security of Payment Act. The document typically includes detailed specifications, payment mechanisms, project timelines, quality standards, and dispute resolution procedures, while addressing specific requirements of Singapore's building authorities.

What sections should be included in a Construction Agreement Between Owner And Contractor?

1. Parties: Identifies and defines the Owner and Contractor with full legal names and addresses

2. Background: Describes the context of the construction project and the parties' intentions

3. Definitions: Defines key terms used throughout the agreement

4. Scope of Work: Detailed description of the construction work to be performed

5. Contract Sum and Payment Terms: Specifies the total contract value and payment schedule

6. Project Timeline: Construction schedule, milestones, and completion dates

7. Contractor's Obligations: Key responsibilities and duties of the contractor

8. Owner's Obligations: Key responsibilities and duties of the owner

9. Insurance and Securities: Required insurance coverage and performance securities

10. Variations: Process for handling changes to scope or specifications

What sections are optional to include in a Construction Agreement Between Owner And Contractor?

1. Liquidated Damages: Compensation for delay or breach - recommended for larger projects or when specific completion dates are critical

2. Performance Bond: Security for contractor's performance - recommended for high-value projects or when required by law

3. Defects Liability Period: Extended warranty period after completion - recommended for complex construction projects

4. Environmental Compliance: Specific environmental requirements - recommended when project has significant environmental impact

What schedules should be included in a Construction Agreement Between Owner And Contractor?

1. Schedule 1: Drawings and Specifications: Detailed technical specifications and architectural drawings

2. Schedule 2: Bill of Quantities: Itemized list of materials and quantities

3. Schedule 3: Payment Schedule: Detailed breakdown of payment milestones

4. Schedule 4: Project Timeline: Detailed construction schedule with milestones

5. Schedule 5: Insurance Requirements: Detailed insurance specifications and coverage amounts

6. Appendix A: Safety Requirements: Specific safety protocols and requirements

7. Appendix B: Quality Control Procedures: Quality assurance and control specifications

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Cost

Free to use

Relevant legal definitions

Clauses

Relevant Industries

Residential Construction
Commercial Construction
Industrial Construction
Infrastructure

Relevant Teams

Legal
Operations
Procurement
Finance
Quality Control
Risk Management
Construction
Compliance

Relevant Roles

Construction Manager
Property Developer
Project Director
Contract Manager
Site Supervisor
Legal Counsel
Quantity Surveyor
Risk Manager

Industries

Building Control Act: Primary legislation governing building works, structural requirements, and construction standards in Singapore

Building Control Regulations: Detailed regulations specifying technical requirements, procedures, and standards for construction works

Building Maintenance and Strata Management Act: Legislation governing the maintenance of buildings and common property management

Contract Law Act 1961: Foundation law governing formation and enforcement of contracts in Singapore

Misrepresentation Act: Law dealing with false statements made during contract formation and remedies

Third Parties (Rights against Insurers) Act: Legislation protecting rights of third parties in insurance claims

Workplace Safety and Health Act: Comprehensive legislation ensuring safety, health, and welfare of persons at workplaces

Work Injury Compensation Act: Law governing compensation for workplace injuries and occupational diseases

Employment Act: Main labor law governing employment terms and conditions

Building and Construction Industry Security of Payment Act: Legislation facilitating payments for construction work and related goods/services

Environmental Protection and Management Act: Law controlling environmental pollution and protecting environmental public health

Environmental Public Health Act: Legislation maintaining environmental public health standards in construction

Professional Engineers Act: Law regulating professional engineering services and standards

Architects Act: Legislation governing architectural services and professional standards

BCA Regulations: Building and Construction Authority's specific regulations for construction industry

Code of Practice for Building Works: Technical standards and guidelines for building works in Singapore

Singapore Standards (SS): National standards for construction materials, methods, and practices

Arbitration Act: Law governing arbitration proceedings for dispute resolution

Mediation Act: Framework for conducting mediation proceedings in Singapore

Contractors' All Risks Insurance: Mandatory insurance covering construction works and third-party liability

Public Liability Insurance: Insurance covering third-party claims for property damage or personal injury

Work Injury Compensation Insurance: Mandatory insurance covering worker injury compensation claims

Find the exact document you need

No matches found.

Subcontractor Service Agreement

A Singapore-law governed agreement defining terms and conditions for subcontractor services, including scope, payment, and compliance requirements.

How Cambridge United Uses Genie AI to Speed Up Player Signings and Slash Legal Costs

Generate a Bespoke Document

Download a Standard Template

What is a Construction Agreement Between Owner And Contractor?

What sections should be included in a Construction Agreement Between Owner And Contractor?

What sections are optional to include in a Construction Agreement Between Owner And Contractor?

What schedules should be included in a Construction Agreement Between Owner And Contractor?

Authors

Alex Denne

Jurisdiction

Publisher

Document Type

Sector

Cost

Find the exact document you need

Subcontractor Service Agreement

Subcontractor Employment Agreement

Sole Trader Contract

Simple Subcontractor Contract

Simple Payment Agreement Contract

Residential Contractor Agreement

Pre Agreement Contract

Painting Contract Agreement

Independent Contractor And Non Compete

Foreign Independent Contractor Agreement

Driver Contractor Agreement

Domestic Subcontract Agreement

Contractor Service Agreement

Contractor Referral Agreement

Contract For Personal Service

Contract For Labor Agreement

Contract Between Employer And Independent Contractor

Consulting Agreement Contract

Construction Contractor Contract

Civil Work Contract Agreement

Subcontractor Hold Harmless Agreement

Salon Contract For Employees

Part Time Contractor Agreement

Mining Contractor Agreement

Home Remodel Contract

Framework Agreement Contract

Construction Warranty Agreement

Construction Service Contract

Contract Agreement Between Two Parties

Construction Contract Agreement Form

Binding Agreement Contract

Agreement Security Guard Contract

Agreement For Construction Of House

Agreement Between Contractor And Principal Employer

Independent Contractor Equity Agreement

Model Form Contract

Company Bond Contract

Construction Owner's Representative Contract

Profit Sharing Agreement Independent Contractor

Loan Officer Independent Contractor Agreement

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security:

Use Cases

Generate Legal Docs Free