Building Contract Agreement for Saudi Arabia

Building Contract Agreement Template for Saudi Arabia

A comprehensive legal agreement governed by Saudi Arabian law that establishes the terms and conditions for construction projects within the Kingdom. This document outlines the rights, obligations, and responsibilities of both the employer and contractor, incorporating requirements from the Saudi Building Code, local municipality regulations, and Sharia principles. It covers crucial aspects including scope of works, payment terms, project timeline, quality standards, safety requirements, and dispute resolution mechanisms, while ensuring compliance with local content requirements and cultural considerations specific to Saudi Arabia.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Generate a Bespoke Document

1. Select your governing law:

2. Enter your key requirements:

3. Create your document to edit, review or download

Download a Standard Template

Get our Saudi Arabia-compliant Building Contract Agreement

4.6 / 5

4.8 / 5

Alternatively: Run an advanced review of an existing
Building Contract Agreement

Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

Upload your Doc

What is a Building Contract Agreement?

The Building Contract Agreement serves as the primary legal instrument for construction projects in Saudi Arabia, establishing the contractual relationship between the employer and contractor. It is essential for any construction project in the Kingdom, whether residential, commercial, or industrial. The document incorporates requirements from Saudi law, including the Saudi Building Code, Labor Law, and environmental regulations, while ensuring Sharia compliance. It typically includes detailed specifications of the works, payment mechanisms, timeline commitments, quality standards, and risk allocation provisions. This agreement is particularly crucial given Saudi Arabia's ambitious development projects under Vision 2030 and the need for clear, comprehensive contractual frameworks that protect all parties' interests while facilitating efficient project execution.

What sections should be included in a Building Contract Agreement?

1. Parties: Identification of the contracting parties - the employer and the contractor, including their full legal names, registration details, and addresses

2. Background: Context of the agreement, including project overview and basis for the contract

3. Definitions: Detailed definitions of terms used throughout the contract, including technical construction terms and legal terminology

4. Scope of Works: Detailed description of the construction works to be performed, including specifications and standards

5. Contract Price and Payment: Terms of payment, including price, payment schedule, variations, and payment mechanisms compliant with Saudi banking regulations

6. Project Timeline: Construction schedule, completion dates, milestones, and provisions for extensions of time

7. Contractor Obligations: Detailed responsibilities of the contractor, including workforce, materials, equipment, and compliance with local regulations

8. Employer Obligations: Responsibilities of the employer, including site access, permits, and approvals

9. Quality and Standards: Required quality standards, inspections, and compliance with Saudi Building Code

10. Health, Safety and Environment: HSE requirements and compliance with Saudi regulations

11. Insurance and Securities: Required insurance coverage and performance securities

12. Variations: Procedures for handling changes to the scope of work

13. Defects Liability: Defects liability period and remediation procedures

14. Termination: Grounds and procedures for contract termination

15. Dispute Resolution: Procedures for dispute resolution, including reference to Saudi courts or arbitration

16. Governing Law: Confirmation of Saudi law as governing law and reference to Sharia compliance

What sections are optional to include in a Building Contract Agreement?

1. Design Obligations: Required when contractor has design responsibilities in design-build contracts

2. Subcontracting: Include when subcontracting is permitted, specifying approval requirements and limitations

3. Materials Storage: Include for projects requiring significant materials storage or staging areas

4. Force Majeure: Detailed force majeure provisions for high-risk or long-term projects

5. Intellectual Property: Include when design or innovative construction methods are involved

6. Confidentiality: Required for projects involving sensitive information or proprietary methods

7. Government Approvals: Detailed section needed for projects requiring specific governmental permissions

8. Environmental Protection: Extended provisions for projects with significant environmental impact

9. Local Content Requirements: Include when project must meet Saudi Arabia's local content requirements

10. Warranties: Additional warranties beyond standard defects liability period

What schedules should be included in a Building Contract Agreement?

1. Schedule 1 - Works Specification: Detailed technical specifications of the construction works

2. Schedule 2 - Site Plans and Drawings: Architectural, structural, and other technical drawings

3. Schedule 3 - Project Timeline: Detailed construction schedule with milestones

4. Schedule 4 - Price Schedule: Breakdown of contract price, including bill of quantities

5. Schedule 5 - Payment Schedule: Payment milestones and procedures

6. Schedule 6 - Key Personnel: List of key personnel from both parties with roles and responsibilities

7. Schedule 7 - Required Insurances: Details of required insurance coverage

8. Schedule 8 - Forms of Securities: Templates for performance bonds and other securities

9. Schedule 9 - Quality Assurance Plan: Detailed quality control procedures and requirements

10. Schedule 10 - HSE Requirements: Detailed health, safety, and environmental requirements

11. Appendix A - Permits and Licenses: Copies of relevant permits and licenses

12. Appendix B - Testing and Commissioning Procedures: Procedures for testing and commissioning of completed works

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Cost

Free to use

Relevant legal definitions

Clauses

Relevant Industries

Construction

Real Estate Development

Infrastructure

Commercial Property

Residential Property

Industrial Development

Healthcare Facilities

Education Facilities

Hospitality

Retail

Religious Buildings

Government Buildings

Transportation

Energy

Manufacturing

Relevant Teams

Legal

Construction

Project Management

Commercial

Procurement

Finance

Operations

Technical

Risk Management

Quality Assurance

Health and Safety

Compliance

Business Development

Contract Administration

Relevant Roles

Chief Executive Officer

Managing Director

Construction Director

Project Director

Legal Counsel

Contract Manager

Project Manager

Site Manager

Quantity Surveyor

Construction Manager

Commercial Manager

Procurement Manager

Risk Manager

Finance Director

Technical Director

Operations Manager

Health and Safety Manager

Quality Assurance Manager

Compliance Officer

Business Development Manager

Find the exact document you need

No matches found.

Selling Real Estate Contract

A Saudi Arabian real estate sales contract template compliant with local laws and Sharia principles, facilitating property transfers and ensuring regulatory compliance.

How Cambridge United Uses Genie AI to Speed Up Player Signings and Slash Legal Costs

Generate a Bespoke Document

Download a Standard Template

What is a Building Contract Agreement?

What sections should be included in a Building Contract Agreement?

What sections are optional to include in a Building Contract Agreement?

What schedules should be included in a Building Contract Agreement?

Authors

Alex Denne

Jurisdiction

Publisher

Document Type

Sector

Cost

Find the exact document you need

Selling Real Estate Contract

Wholesaling Real Estate Contract

Non Binding Agreement

Non Compete Form

Agreement For Job Work

Non Disclosure Form

Videography Contract

Subscription Agreement

Production Contract

Novation Agreement (Real Estate)

Option Contract (Real Estate)

Labor Contract

Franchise Agreement

Common Agreement

Barter Agreement

Unregistered Sale Agreement With Possession

Master Contract

Notarial Contract

House Rent Agreement Form

Partnership Agreement Form

Landscape Contract

Guarantee Contract

Tenancy Agreement Form

Simple Rental Agreement Form

Money Agreement Between Two Parties

Side Agreement

Novation Contract

Mutual Agreement Between Two Parties

Contract For Selling A Car

Business Transfer Agreement

Tooling Agreement

Representation Agreement

Notary Rent Agreement

Non Compete Agreement Between Companies

Land Agreement Between Two Parties

Buyer Agency Agreement

Commercial Lease Form

Vending Machine Contract

Contra Agreement

Catering Contract

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security:

Use Cases

Generate Legal Docs Free