All Countries
Procurement
Roofing Subcontractor Contract

Roofing Subcontractor Contract Template for Nigeria

Create a bespoke document in minutes,  or upload and review your own.

4.6 / 5
4.8 / 5

Let's create your Roofing Subcontractor Contract

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Roofing Subcontractor Contract

"I need a Roofing Subcontractor Contract for a large commercial development project in Lagos, Nigeria, where we'll be installing solar-integrated roofing systems across multiple buildings starting March 2025, with specific focus on environmental compliance and local content requirements."

Celebrated by
Collaborations with
Investors
Document background
The Roofing Subcontractor Contract is essential for construction projects in Nigeria where specialized roofing work is required to be performed by a qualified subcontractor. This document is typically used when a main contractor needs to delegate roofing works to a specialized contractor while maintaining overall project responsibility. The agreement ensures compliance with Nigerian construction laws, safety regulations, and industry standards while protecting both parties' interests. It includes detailed specifications for materials, workmanship, payment terms, and project timelines, along with provisions for insurance, warranties, and dispute resolution. The document is particularly important given Nigeria's specific requirements for construction contracts, local content laws, and safety regulations in the construction industry.
Suggested Sections

1. Parties: Identifies the main contractor and roofing subcontractor with full legal names and addresses

2. Background: Brief context of the main construction project and the need for roofing subcontractor services

3. Definitions: Defines key terms used throughout the contract including technical roofing terms

4. Scope of Work: Detailed description of the roofing work to be performed, including type of roof, materials, and area coverage

5. Contract Price and Payment Terms: Specifies the total contract sum, payment schedule, and conditions for payment

6. Timeline and Completion: Sets out project schedule, milestones, and completion requirements

7. Materials and Workmanship: Specifies quality standards, material requirements, and workmanship warranties

8. Safety Requirements: Details safety protocols, PPE requirements, and compliance with Nigerian safety regulations

9. Insurance and Indemnity: Specifies required insurance coverage and indemnification obligations

10. Warranties and Defects Liability: Details warranty period and obligations to rectify defects

11. Termination: Conditions and procedures for contract termination

12. Dispute Resolution: Procedures for handling disputes, including arbitration provisions

13. Governing Law: Specifies Nigerian law as governing law and relevant jurisdiction

14. Force Majeure: Provisions for unforeseen circumstances preventing contract performance

15. Notices: Procedures for formal communications between parties

Optional Sections

1. Environmental Compliance: Required when project involves specific environmental requirements or certifications

2. Local Content Requirements: Needed when project must comply with Nigerian local content laws

3. Performance Bond: Include when a performance bond is required for the project

4. Advance Payment Guarantee: Required when advance payments are made to the subcontractor

5. Variations: Include detailed variation procedures for larger or complex projects

6. Liquidated Damages: Include for projects with critical completion deadlines

7. Site Access and Security: Required for projects with specific site access restrictions or security requirements

Suggested Schedules

1. Schedule 1: Scope of Works: Detailed technical specifications and drawings for the roofing work

2. Schedule 2: Bill of Quantities: Itemized list of materials, quantities, and prices

3. Schedule 3: Project Timeline: Detailed project schedule with milestones and completion dates

4. Schedule 4: Safety Procedures: Specific safety protocols and requirements for the roofing work

5. Schedule 5: Quality Control Requirements: Detailed quality standards and inspection procedures

6. Schedule 6: Payment Schedule: Detailed breakdown of payment milestones and amounts

7. Appendix A: Insurance Requirements: Specific insurance types and coverage amounts required

8. Appendix B: Required Permits and Licenses: List of required permits and licenses for the work

9. Appendix C: Form of Performance Bond: Standard form for performance bond if required

10. Appendix D: Technical Drawings: Detailed roofing plans and technical drawings

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Linkedin in social icon imageX social icon image
alex.den.21@genieai.co
Relevant legal definitions
Agreement
Applicable Laws
Approved Drawing(s)
Bill of Quantities
Commencement Date
Completion Certificate
Completion Date
Contract Price
Contract Documents
Defects Liability Period
Delay Events
Force Majeure
Good Industry Practice
Main Contract
Main Contractor
Materials
Method Statement
Payment Certificate
Performance Bond
Practical Completion
Project
Project Manager
Project Site
Quality Standards
Retention Money
Roofing Works
Safety Requirements
Schedule of Rates
Scope of Works
Site Instructions
Specifications
Subcontractor
Substantial Completion
Technical Drawings
Variation
Warranty Period
Work Programme
Workmanship
Works
Employer
Nigerian Industrial Standards
Health and Safety Plan
PPE Requirements
Construction Timeline
Progress Report
Quality Control Plan
Risk Assessment
Site Access Hours
Storage Area
Working Days
Clauses
Definitions
Scope of Work
Contract Price
Payment Terms
Project Timeline
Health and Safety
Materials and Equipment
Quality Control
Warranties
Insurance
Indemnification
Performance Security
Variations
Delay and Extensions of Time
Suspension
Termination
Force Majeure
Dispute Resolution
Governing Law
Confidentiality
Assignment and Subcontracting
Site Access
Compliance with Laws
Environmental Protection
Local Content Requirements
Documentation and Reporting
Defects Liability
Intellectual Property
Notices
Risk Allocation
Liquidated Damages
Workmanship Standards
Testing and Inspection
Storage and Security
Labor Requirements
Relevant Industries

Construction

Real Estate

Infrastructure Development

Commercial Property

Residential Property

Industrial Construction

Government Buildings

Educational Facilities

Healthcare Facilities

Retail Development

Relevant Teams

Legal

Operations

Procurement

Construction

Project Management

Commercial

Risk & Compliance

Health & Safety

Technical

Contract Administration

Relevant Roles

Construction Manager

Project Manager

Contract Manager

Legal Counsel

Quantity Surveyor

Site Supervisor

Safety Officer

Procurement Manager

Operations Director

Commercial Manager

Risk Manager

Technical Director

Chief Engineer

Construction Director

Compliance Officer

Industries
Labour Act, Chapter L1, Laws of the Federation of Nigeria 2004: Governs employment relationships, working conditions, wages, and general labor rights in Nigeria. Essential for defining the contractor relationship and worker protections.
Factories Act, Cap F1 LFN 2004: Provides regulations for workplace safety and health standards, particularly relevant for construction and roofing work at heights.
National Building Code 2006: Sets standards for building construction, including roofing specifications, materials, and safety requirements.
Companies and Allied Matters Act (CAMA) 2020: Regulates business operations and corporate entities in Nigeria, relevant for business registration and contractual capacity.
Environmental Impact Assessment Act: Governs environmental protection requirements, including disposal of construction materials and environmental safety measures.
Nigerian Industrial Standards (NIS): Provides specifications for construction materials and quality standards that must be met in roofing works.
Value Added Tax Act: Governs VAT obligations in construction contracts and material purchases.
Personal Income Tax Act: Relevant for tax obligations of contractors and subcontractors.
Employees Compensation Act 2010: Provides for compensation in case of work-related injuries or accidents, crucial for high-risk construction work.
Public Procurement Act 2007: Relevant if the project involves public contracts or government buildings.
Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Subcontractor Offer Letter

A formal offer letter from a main contractor to a subcontractor under Nigerian law, outlining key terms and conditions for project-specific work.

find out more

Contractor Subcontractor Agreement

A Nigerian law-governed agreement between a main contractor and subcontractor defining work scope, payment terms, and mutual obligations for project execution.

find out more

Nominated Subcontractor Contract

A Nigerian law-governed contract between a Main Contractor and Employer-selected Nominated Subcontractor, detailing works, payments, and obligations.

find out more

Roofing Subcontractor Contract

A Nigerian law-governed agreement between a main contractor and roofing subcontractor for specialized roofing works, incorporating local construction regulations and safety requirements.

find out more

Plumbing Subcontractor Agreement

A Nigerian law-governed agreement between a main contractor and plumbing subcontractor for the provision of plumbing works and related services.

find out more

Security Subcontractor Agreement

A Nigerian law-governed agreement establishing terms for security subcontractor services, including regulatory compliance, operational procedures, and service standards.

find out more

Independent Subcontractor Agreement

A Nigerian law-governed agreement establishing terms and conditions between a company and an independent subcontractor, defining service scope and maintaining contractor independence.

find out more

Independent Contractor Subcontractor Agreement

A Nigerian law-governed agreement establishing terms between a primary contractor and an independent contractor subcontractor for service provision.

find out more

Download our whitepaper on the future of AI in Legal

By providing your email address you are consenting to our Privacy Notice.
Thank you for downloading our whitepaper. This should arrive in your inbox shortly. In the meantime, why not jump straight to a section that interests you here: https://www.genieai.co/our-research
Oops! Something went wrong while submitting the form.

Genie’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; Genie’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

Our bank-grade security infrastructure undergoes regular external audits

We are ISO27001 certified, so your data is secure

Organizational security

You retain IP ownership of your documents

You have full control over your data and who gets to see it

Innovation in privacy:

Genie partnered with the Computational Privacy Department at Imperial College London

Together, we ran a £1 million research project on privacy and anonymity in legal contracts

Want to know more?

Visit our Trust Centre for more details and real-time security updates.

Read our Privacy Policy.