The Electrical Contractor Contract is a vital legal instrument used in Malaysia when engaging professional electrical services for installation, maintenance, or repair work. This document is essential for projects requiring licensed electrical work, from small commercial installations to large industrial projects. The contract ensures compliance with Malaysian regulations, particularly the Electricity Supply Act 1990 and associated regulations, while protecting both parties' interests. It includes detailed specifications of work scope, safety requirements, payment terms, and quality standards. The document is designed to meet the requirements of the Energy Commission of Malaysia and local authorities, incorporating necessary technical specifications and safety protocols. This type of contract is particularly important given Malaysia's strict regulatory environment for electrical works and the need for proper documentation of electrical installations for insurance and liability purposes.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification of the contracting parties including the client and the electrical contractor, with their full legal names, registration numbers, and addresses
2. Background: Context of the agreement including the project overview and the contractor's qualifications and licenses
3. Definitions: Definitions of key terms used throughout the contract, including technical electrical terms and standard contractual terminology
4. Scope of Works: Detailed description of the electrical works to be performed, including specific installations, repairs, or maintenance services
5. Contractor's Obligations: Key responsibilities of the electrical contractor, including compliance with regulations, safety standards, and quality requirements
6. Client's Obligations: Responsibilities of the client, including site access, necessary approvals, and cooperation requirements
7. Project Timeline: Schedule of works, including commencement date, completion date, and key milestones
8. Payment Terms: Detailed payment structure, including contract sum, payment schedule, and payment conditions
9. Safety and Compliance: Safety requirements and compliance with Malaysian electrical regulations and standards
10. Insurance and Liability: Insurance requirements and allocation of risks between parties
11. Warranties: Warranties for workmanship and materials, including duration and scope
12. Termination: Conditions and procedures for contract termination by either party
13. Dispute Resolution: Procedures for handling disputes, including mediation and arbitration processes
14. General Provisions: Standard contract clauses including notices, governing law, and entire agreement
1. Variation Procedures: Procedures for handling changes to the scope of work - include when variations are likely
2. Testing and Commissioning: Detailed procedures for testing and commissioning of electrical installations - include for larger installations
3. Maintenance Services: Terms for ongoing maintenance services - include if post-installation maintenance is part of the contract
4. Environmental Protection: Specific environmental protection measures - include for projects with significant environmental impact
5. Subcontracting: Terms governing the use of subcontractors - include for larger projects requiring specialized work
6. Force Majeure: Provisions for unforeseen circumstances - include for longer-term or high-value contracts
7. Intellectual Property: Protection of designs and technical solutions - include when custom electrical solutions are being developed
1. Schedule 1 - Technical Specifications: Detailed technical specifications of all electrical works to be performed
2. Schedule 2 - Bill of Quantities: Itemized list of materials, equipment, and labor with associated costs
3. Schedule 3 - Project Timeline: Detailed project schedule with milestones and completion dates
4. Schedule 4 - Safety Procedures: Specific safety procedures and protocols for the electrical works
5. Schedule 5 - Drawings and Plans: Technical drawings, electrical layouts, and installation plans
6. Schedule 6 - Testing Protocols: Detailed procedures for testing and certifying electrical installations
7. Schedule 7 - Warranties and Guarantees: Specific terms of warranties for different components and works
8. Appendix A - Licenses and Certifications: Copies of relevant licenses, permits, and certifications
9. Appendix B - Insurance Certificates: Copies of required insurance policies and certificates
Relevant legal definitions
Agreement
Approval
Competent Person
Completion Certificate
Contract Price
Contract Documents
Completion Date
Commencement Date
Defects Liability Period
Electrical Installation
Electrical Works
Energy Commission
Force Majeure
Good Industry Practice
Installation Site
License
Materials
Milestone
Payment Schedule
Performance Bond
Permit
Project Manager
Project Schedule
Quality Standards
Regulatory Requirements
Safety Regulations
Scope of Works
Services
Specifications
Subcontractor
Technical Drawings
Testing Certificate
Variation Order
Warranty Period
Work Site
Approval
Competent Person
Completion Certificate
Contract Price
Contract Documents
Completion Date
Commencement Date
Defects Liability Period
Electrical Installation
Electrical Works
Energy Commission
Force Majeure
Good Industry Practice
Installation Site
License
Materials
Milestone
Payment Schedule
Performance Bond
Permit
Project Manager
Project Schedule
Quality Standards
Regulatory Requirements
Safety Regulations
Scope of Works
Services
Specifications
Subcontractor
Technical Drawings
Testing Certificate
Variation Order
Warranty Period
Work Site
Clauses
Interpretation
Appointment
Scope of Works
Contract Price
Payment Terms
Project Timeline
Contractor Obligations
Client Obligations
Health and Safety
Regulatory Compliance
Quality Standards
Testing and Commissioning
Materials and Equipment
Site Access
Warranties
Insurance
Indemnification
Liability
Intellectual Property
Confidentiality
Force Majeure
Termination
Dispute Resolution
Notices
Assignment
Subcontracting
Variations
Performance Security
Defects Liability
Environmental Protection
Record Keeping
Governing Law
Entire Agreement
Appointment
Scope of Works
Contract Price
Payment Terms
Project Timeline
Contractor Obligations
Client Obligations
Health and Safety
Regulatory Compliance
Quality Standards
Testing and Commissioning
Materials and Equipment
Site Access
Warranties
Insurance
Indemnification
Liability
Intellectual Property
Confidentiality
Force Majeure
Termination
Dispute Resolution
Notices
Assignment
Subcontracting
Variations
Performance Security
Defects Liability
Environmental Protection
Record Keeping
Governing Law
Entire Agreement
Relevant Industries
Construction
Real Estate
Manufacturing
Industrial
Commercial
Residential
Healthcare
Education
Retail
Hospitality
Data Centers
Telecommunications
Infrastructure
Mining
Oil and Gas
Relevant Teams
Legal
Procurement
Facilities Management
Operations
Project Management
Engineering
Compliance
Risk Management
Property Management
Construction Management
Building Services
Technical Services
Health and Safety
Relevant Roles
Facilities Manager
Project Manager
Procurement Manager
Contract Administrator
Chief Operating Officer
Technical Director
Electrical Engineer
Construction Manager
Property Manager
Operations Manager
Legal Counsel
Risk Manager
Compliance Officer
Safety Officer
Maintenance Manager
Building Services Manager
Find the exact document you need
Home Builder Subcontractor Agreement
A Malaysian law-governed agreement between main contractor and subcontractor for residential construction works, complying with local construction and housing development regulations.
find out more
Contractor Service Contract
Malaysian law-governed agreement establishing terms between a company and independent contractor, defining service provisions and relationship parameters.
find out more
Independent Contractor Therapist Agreement
Malaysian-law governed agreement establishing an independent contractor relationship between a healthcare facility and a therapist.
find out more
Contractor Architect Agreement
A Malaysian law-governed agreement between a client and an architect contractor defining architectural services, obligations, and commercial terms.
find out more
Contract For Work For Hire
A Malaysian law-governed agreement establishing terms for commissioned work, including ownership transfer, payment, and delivery obligations.
find out more
Simple Building Contract
A Malaysian law-governed construction agreement for straightforward building projects, establishing key terms between employer and contractor.
find out more
Basic Independent Contractor Agreement
A Malaysian law-governed agreement establishing the terms and conditions between a business and an independent contractor, ensuring clear definition of services and compliance with local regulations.
find out more
Self Employed Service Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a service provider and client company, defining services, terms, and obligations.
find out more
Contractor Deposit Agreement
A Malaysian law-governed agreement establishing terms for contractor deposits in construction projects, including payment, holding, and release conditions.
find out more
Developer Contractor Agreement
Malaysian-law governed agreement for engaging software development contractors, defining service terms and protecting both parties' interests.
find out more
Home Contractor Contract
A Malaysian law-governed contract between homeowner and contractor for residential construction works, including terms, conditions, and regulatory compliance requirements.
find out more
Standard Independent Contractor Contract
A Malaysian law-governed agreement establishing terms and conditions between a company and an independent contractor for professional services.
find out more
Agreement Between Owner And Electrical Contractor
A Malaysian law-governed agreement between property owner and electrical contractor defining terms, scope, and compliance requirements for electrical installation works.
find out more
Service Of Work Contract
A Malaysian law-governed agreement establishing terms and conditions for service provision between a service provider and client.
find out more
Residential Building Contract Agreement
A Malaysian law-governed agreement between property owner and contractor for residential construction works, ensuring compliance with local construction regulations and standards.
find out more
Agreement Between Owner And Labour Contractor
A Malaysian law-governed agreement between project owners and labor contractors establishing terms for workforce services and regulatory compliance.
find out more
Massage Contractor Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a business and a massage therapist, defining service terms and operational requirements.
find out more
Short Form Contractor Agreement
A streamlined contractor agreement template for Malaysian jurisdiction, designed for engaging independent contractors or service providers.
find out more
Home Painting Contract
A Malaysian law-governed contract for residential painting services, establishing terms between contractors and property owners.
find out more
Home Improvement Agreement
A Malaysian law-governed agreement between homeowner and contractor for residential improvement works, detailing project scope, terms, and obligations.
find out more
Freelance Contractor Agreement
A Malaysian law-governed agreement establishing terms between a client and freelance contractor, defining services, payments, and obligations.
find out more
Subcontractor Employment Agreement
Malaysian-law governed agreement establishing subcontractor relationship and terms of service provision.
find out more
Simple Payment Agreement Contract
A Malaysian law-governed agreement establishing payment terms and obligations between parties.
find out more
Independent Contractor And Non Compete
Malaysian law-compliant agreement for engaging independent contractors with non-compete provisions to protect business interests.
find out more
Contractor Service Agreement
A Malaysian law-governed agreement establishing terms and conditions between a client company and an independent contractor for professional services.
find out more
Consulting Agreement Contract
A Malaysian law-governed agreement defining the terms and conditions between a consultant and client, including service scope, payments, and obligations.
find out more
Standard Form Of Contract For Maintenance And Renovation Works
A Malaysian standard form contract template for maintenance and renovation works, establishing terms and conditions between property owners and contractors.
find out more
Standard Builders Contract
A Malaysian law-governed construction contract defining the relationship between employer and contractor for building projects, aligned with CIDB requirements.
find out more
Simple Contractor Contract
A Malaysian law-governed contractor agreement establishing independent service provider relationships while ensuring legal compliance and protecting both parties' interests.
find out more
Self Employed Cleaner Contract
Malaysian-compliant contract template for engaging self-employed cleaning contractors, establishing service terms and independent contractor status.
find out more
Sales Subcontractor Agreement
Malaysian-law governed agreement establishing terms for sales subcontractor relationships, including commission structures, territories, and performance requirements.
find out more
Percentage Agreement Contract
A Malaysian law-governed agreement establishing percentage-based commercial terms between parties, including calculation methods and payment structures.
find out more
Painting Subcontractor Contract
A Malaysian law-governed contract establishing terms and conditions for painting subcontractor works in construction projects.
find out more
Part Time Contractor Agreement
Malaysian-law governed agreement for engaging part-time independent contractors, defining service terms and maintaining contractor independence.
find out more
General Contract For Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for service provision between a provider and client.
find out more
General Contract Agreement Between Two Parties
A versatile contract template under Malaysian law establishing legal terms and conditions between two contracting parties.
find out more
Contract For Cleaning Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for professional cleaning services between service providers and clients.
find out more
Construction Service Contract
A Malaysian law-governed agreement establishing terms and conditions for construction services between an employer and contractor.
find out more
Contract Agreement For Interior Works
A Malaysian law-governed agreement establishing terms and conditions for interior works projects, including scope, payments, and obligations of all parties.
find out more
Contractor Non Solicitation Agreement
A Malaysian law-governed agreement preventing contractors from soliciting company employees, clients, or customers during and after their engagement.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)