Concrete Contractor Contract Template for Canada

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Concrete Contractor Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Concrete Contractor Contract

I need a Concrete Contractor Contract for a large commercial warehouse project starting March 2025, requiring specialized concrete flooring with load-bearing capacity of 5000 PSI and strict timeline requirements for phased completion.

Document background

The Concrete Contractor Contract is a specialized construction agreement used in Canadian jurisdictions when engaging professional concrete contractors for construction projects. This document is essential for projects involving concrete work, including foundations, structural elements, pavements, and decorative concrete installations. The contract addresses the unique aspects of concrete construction, including material specifications, curing requirements, weather considerations, and quality control measures. It incorporates relevant Canadian federal and provincial construction laws, building codes, and safety regulations, while providing clear terms for payment, performance, and dispute resolution. This contract type is particularly important given the permanent nature of concrete work and the need for precise specifications and quality standards to ensure structural integrity and durability.

Suggested Sections

1. Parties: Identification of the contractor and client, including full legal names, addresses, and business registration details

2. Background: Context of the agreement and general purpose of the concrete construction work

3. Definitions: Definitions of key terms used throughout the contract, including technical concrete-related terminology

4. Scope of Work: Detailed description of concrete work to be performed, including type of concrete work, location, and general specifications

5. Contract Price and Payment Terms: Total contract value, payment schedule, deposit requirements, and terms for progress payments

6. Timeline and Completion: Project schedule, start date, completion date, and provisions for delays

7. Materials and Equipment: Specifications for concrete materials, equipment to be used, and quality standards

8. Workmanship and Quality Standards: Required standards for concrete work, including references to applicable building codes and industry standards

9. Health and Safety Requirements: Safety protocols, compliance with safety regulations, and protective measures

10. Permits and Compliance: Responsibility for obtaining necessary permits and ensuring compliance with local building codes

11. Warranties and Guarantees: Warranties on concrete work, duration of coverage, and conditions

12. Insurance and Liability: Required insurance coverage and allocation of liability between parties

13. Termination: Conditions and procedures for contract termination by either party

14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

15. General Provisions: Standard contract clauses including governing law, notices, and entire agreement

Optional Sections

1. Site Preparation Requirements: Used when the contractor is responsible for site preparation before concrete work

2. Subcontractor Provisions: Required when subcontractors will be used for portions of the work

3. Environmental Protection Measures: Included for projects with specific environmental concerns or requirements

4. Weather Conditions and Delays: Important for outdoor concrete work where weather significantly impacts the project

5. Storage and Security: Needed when materials or equipment must be stored on-site

6. Testing and Inspection: Required for projects with specific quality control requirements or third-party testing

7. Concrete Mix Design: Used when specific concrete specifications are crucial to the project

8. Property Access and Working Hours: Important for projects in residential areas or with specific access restrictions

9. Waste Management: Required for projects with specific requirements for concrete waste disposal

10. Reinforcement Specifications: Needed when steel reinforcement is part of the concrete work

Suggested Schedules

1. Schedule A - Detailed Scope of Work: Comprehensive description of concrete work including drawings, dimensions, and specifications

2. Schedule B - Price Breakdown: Detailed breakdown of costs including materials, labor, and other expenses

3. Schedule C - Project Timeline: Detailed project schedule with milestones and completion dates

4. Schedule D - Material Specifications: Detailed specifications for concrete mix, reinforcement, and other materials

5. Schedule E - Site Plan: Drawings and plans showing work location and site layout

6. Schedule F - Safety Protocol: Detailed safety procedures and requirements specific to the project

7. Schedule G - Quality Control Requirements: Testing procedures, acceptance criteria, and quality control measures

8. Schedule H - Insurance Certificates: Copies of required insurance policies and certificates

9. Appendix 1 - Required Permits: Copies of building permits and other required authorizations

10. Appendix 2 - Warranty Certificate: Detailed warranty terms and conditions for the concrete work

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Construction

Real Estate Development

Infrastructure

Industrial Construction

Commercial Construction

Residential Development

Municipal Infrastructure

Manufacturing

Warehousing

Transportation Infrastructure

Educational Facilities

Healthcare Facilities

Relevant Teams

Legal

Procurement

Construction Management

Project Management

Operations

Quality Assurance

Health and Safety

Risk Management

Facilities Management

Contract Administration

Property Management

Development

Relevant Roles

Construction Manager

Project Manager

Contract Administrator

Legal Counsel

Procurement Manager

Site Supervisor

Quality Control Manager

Safety Coordinator

Construction Estimator

Facilities Manager

Property Manager

Development Manager

Risk Manager

Operations Director

Chief Operating Officer

Find the exact document you need

Joint Venture Agreement Building (Construction)

Canadian-law governed agreement establishing a joint venture between multiple parties for construction project collaboration, including structure, responsibilities, and risk allocation.

How Genie AI reduced drafting time by 75% for a legal firm

Let's create your Concrete Contractor Contract

Authors

Alex Denne

Find the exact document you need

Joint Venture Agreement Building (Construction)

Owner Builder Contractor Agreement

Agreement For Building Contractor

Contractor To Subcontractor Contract

Builder Client Contract

Land Owner Builder Agreement

Contract For House (Construction)

Third Party Agreement (Construction)

Project Management Contract In (Construction)

Project Management Agreement (Construction)

Joint Venture Agreement For (Construction)

Independent Contractor Agreement For (Construction)

Contract Between Builder And Homeowner

Construction Agreement And Sale Agreement

Agreement Between Builder And Owner

Concrete Contractor Contract

Contract Between Contractor And Owner

Standard Contractor Contract

House Building Contract Agreement

Residential Cost Plus Contract

Construction Company Partnership Agreement

Builder And Land Owner Agreement

Standard General Contractor Agreement

Standard Building Contract

Construction Equipment Rental Contract

Contractor Contingency Agreement

Construction Completion Agreement

Construction Agreement Between Client And Contractor

Builder Purchase Agreement

Agreement For Construction Of House With Material

Home Improvement Construction Contract

Pre Construction Purchase Agreement

New Construction Purchase Agreement

Construction Finders Fee Agreement

Collaboration Agreement For Construction Of Building

Simple Residential Construction Contract

Fence Construction Agreement

Construction Disbursement Agreement

Landscape Contractor Contract

Construction Owner's Representative Contract

Owner Subcontractor Agreement

Contract Between Builder And Client

Construction Non Compete Agreement

Building Construction Contract Agreement

Swimming Pool Construction Agreement

Simple Construction Loan Agreement

Owner Builder Subcontractor Agreement

Management Building Contract

Commercial Construction Agreement

Owner Builder Agreement

Construction Referral Fee Agreement

Construction Labor Agreement

Builder Development Agreement

Home Builder Contract

Builder Agreement

Construction Agreement Between Owner And Contractor

Construction Payment Contract

Construction Lease Agreement

New Construction Home Contract

Contract For Contractor And Homeowner

Construction Deposit Agreement

Basic Building Contract

Construction Work Order Agreement

Road Construction Agreement

Construction Employee Contract

Construction Subcontract

General Contractor Agreement With Owner

General Construction Agreement

Pre Construction Agreement

Cost Plus Construction Agreement

Construction Agency Agreement

Subcontractor Agreement (Construction)

Standard Construction Contract

General Contractor Contract

Construction Contract Agreement