Agreement For Building Contractor for Canada

Agreement For Building Contractor Template for Canada

A comprehensive legal agreement governed by Canadian law that establishes the contractual relationship between a property owner and a building contractor for construction services. This document outlines the scope of work, payment terms, timeline, quality standards, and legal obligations of both parties. It incorporates provincial construction lien legislation, workplace safety requirements, and industry standards while providing mechanisms for change orders, dispute resolution, and project completion. The agreement includes provisions for insurance, warranties, and compliance with local building codes and regulations.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Generate a Bespoke Document

1. Select your governing law:

2. Enter your key requirements:

3. Create your document to edit, review or download

Download a Standard Template

Get our Canada-compliant Agreement For Building Contractor

4.6 / 5

4.8 / 5

Alternatively: Run an advanced review of an existing
Agreement For Building Contractor

Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

Upload your Doc

What is a Agreement For Building Contractor?

The Agreement For Building Contractor is a fundamental legal document used in the Canadian construction industry to establish and govern the relationship between property owners and contractors undertaking construction projects. This agreement is essential when engaging a contractor for new construction, renovation, or improvement projects, whether commercial, residential, or industrial. It provides comprehensive coverage of project specifics, including scope, pricing, timelines, quality standards, and risk allocation, while ensuring compliance with federal and provincial construction laws, safety regulations, and building codes. The document protects both parties' interests by clearly defining responsibilities, establishing payment terms, and providing mechanisms for handling changes and disputes. Typically used for projects ranging from moderate to large scale, this agreement can be customized based on project complexity and provincial requirements while maintaining core elements required under Canadian construction law.

What sections should be included in a Agreement For Building Contractor?

1. Parties: Identification and details of the Owner and the Contractor, including full legal names, addresses, and registration numbers

2. Background: Context of the agreement, including brief description of the project and the parties' intentions

3. Definitions: Detailed definitions of key terms used throughout the agreement

4. Scope of Work: Detailed description of the construction work to be performed by the Contractor

5. Contract Price and Payment Terms: Total contract value, payment schedule, progress payments, and holdback requirements

6. Project Timeline: Start date, completion date, project milestones, and provisions for extensions

7. Contractor's Obligations: Key responsibilities including permits, licenses, labor, materials, and compliance with laws

8. Owner's Obligations: Responsibilities of the owner including site access, approvals, and existing site conditions

9. Materials and Workmanship: Standards for materials and work quality, inspection rights, and approval processes

10. Changes and Variations: Process for handling change orders and variations to the original scope

11. Insurance and Indemnity: Required insurance coverage and indemnification obligations

12. Warranties: Contractor's warranties on work quality and materials

13. Default and Termination: Events of default, remedies, and termination procedures

14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

15. General Provisions: Standard clauses including notices, assignment, and governing law

What sections are optional to include in a Agreement For Building Contractor?

1. Health and Safety: Detailed health and safety requirements when project involves specific hazards or complex site conditions

2. Environmental Compliance: Additional environmental obligations when project has significant environmental impacts

3. Security Requirements: Requirements for performance bonds or other security when project value exceeds certain thresholds

4. Subcontractors: Provisions governing subcontractor relationships when subcontracting is permitted

5. Equipment and Tools: Specific provisions about equipment supply and maintenance when significant equipment is involved

6. Site Conditions: Detailed provisions about site conditions when working with challenging or unusual sites

7. Force Majeure: Extended force majeure provisions for projects in areas prone to specific risks

8. Intellectual Property: IP provisions when project involves design elements or innovative construction methods

9. Confidentiality: Detailed confidentiality provisions for projects involving proprietary methods or sensitive information

What schedules should be included in a Agreement For Building Contractor?

1. Schedule A - Scope of Work: Detailed specifications, drawings, and technical requirements of the construction work

2. Schedule B - Payment Schedule: Detailed breakdown of payment amounts, timing, and conditions

3. Schedule C - Project Timeline: Detailed project schedule including milestones and critical path items

4. Schedule D - Site Plan: Drawings and details of the construction site and access points

5. Schedule E - Material Specifications: Detailed specifications for all materials to be used in the project

6. Schedule F - Required Insurance: Specific insurance requirements including coverage types and amounts

7. Schedule G - Forms: Standard forms for change orders, progress payments, and completion certificates

8. Schedule H - Safety Procedures: Detailed safety protocols and procedures

9. Appendix 1 - Permits and Licenses: Copies of all required permits, licenses, and authorizations

10. Appendix 2 - Contractor's Qualifications: Contractor's certificates, licenses, and qualification documents

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Cost

Free to use

Relevant legal definitions

Clauses

Relevant Industries

Construction

Real Estate

Property Development

Infrastructure

Commercial Property

Residential Property

Industrial Development

Retail Development

Healthcare Facilities

Educational Institutions

Hospitality

Manufacturing

Relevant Teams

Legal

Operations

Procurement

Finance

Risk Management

Construction Management

Project Management

Property Development

Facilities Management

Compliance

Health and Safety

Quality Assurance

Contract Administration

Business Development

Real Estate

Relevant Roles

Construction Manager

Project Manager

Contract Administrator

Legal Counsel

Risk Manager

Procurement Manager

Property Developer

Facilities Manager

Operations Director

Chief Financial Officer

Quantity Surveyor

Site Supervisor

Building Inspector

Compliance Officer

Insurance Manager

Development Manager

Real Estate Manager

Business Development Manager

Cost Controller

Health and Safety Officer

Find the exact document you need

No matches found.

Joint Venture Agreement Building (Construction)

Canadian-law governed agreement establishing a joint venture between multiple parties for construction project collaboration, including structure, responsibilities, and risk allocation.

How Cambridge United Uses Genie AI to Speed Up Player Signings and Slash Legal Costs

Generate a Bespoke Document

Download a Standard Template

What is a Agreement For Building Contractor?

What sections should be included in a Agreement For Building Contractor?

What sections are optional to include in a Agreement For Building Contractor?

What schedules should be included in a Agreement For Building Contractor?

Authors

Alex Denne

Jurisdiction

Publisher

Document Type

Sector

Cost

Find the exact document you need

Joint Venture Agreement Building (Construction)

Owner Builder Contractor Agreement

Agreement For Building Contractor

Contractor To Subcontractor Contract

Builder Client Contract

Land Owner Builder Agreement

Contract For House (Construction)

Third Party Agreement (Construction)

Project Management Contract In (Construction)

Project Management Agreement (Construction)

Joint Venture Agreement For (Construction)

Independent Contractor Agreement For (Construction)

Contract Between Builder And Homeowner

Construction Agreement And Sale Agreement

Agreement Between Builder And Owner

Concrete Contractor Contract

Contract Between Contractor And Owner

Standard Contractor Contract

House Building Contract Agreement

Residential Cost Plus Contract

Construction Company Partnership Agreement

Builder And Land Owner Agreement

Standard General Contractor Agreement

Standard Building Contract

Construction Equipment Rental Contract

Contractor Contingency Agreement

Construction Completion Agreement

Construction Agreement Between Client And Contractor

Builder Purchase Agreement

Agreement For Construction Of House With Material

Home Improvement Construction Contract

Pre Construction Purchase Agreement

New Construction Purchase Agreement

Construction Finders Fee Agreement

Collaboration Agreement For Construction Of Building

Simple Residential Construction Contract

Fence Construction Agreement

Construction Disbursement Agreement

Landscape Contractor Contract

Construction Owner's Representative Contract

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security:

Use Cases

Generate Legal Docs Free