The Agreement Construction Work is a fundamental legal instrument used in the South African construction industry to formalize the relationship between property owners/developers and contractors. This document is essential when undertaking any significant construction project, whether commercial, residential, or industrial. It must comply with South African construction law, including the Construction Industry Development Board Act, National Building Regulations, and Occupational Health and Safety Act. The agreement typically includes detailed specifications of the works, pricing structures, project timelines, quality standards, and risk allocation mechanisms. It's particularly important for protecting both parties' interests while ensuring project delivery meets legal requirements and industry standards. The document should be customized based on project scope, complexity, and specific requirements while maintaining compliance with South African construction regulations and best practices.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the Employer and Contractor, including registration numbers and physical addresses
2. Background: Context of the agreement, including project overview and purpose
3. Definitions and Interpretation: Detailed definitions of terms used in the agreement and rules of interpretation
4. Scope of Works: Detailed description of construction works to be performed, including specifications and standards
5. Contract Price and Payment Terms: Amount payable, payment schedule, retention amounts, and invoicing procedures
6. Project Timeline: Commencement date, completion date, project milestones, and provisions for extensions of time
7. Contractor Obligations: Primary responsibilities including workmanship, materials, compliance with laws and regulations
8. Employer Obligations: Responsibilities including site access, permits, approvals, and information provision
9. Health and Safety: Safety requirements, compliance with OHS Act, safety officers, and reporting procedures
10. Quality Control: Quality standards, inspections, testing procedures, and approval processes
11. Variations: Process for handling changes to scope, pricing, and timeline
12. Warranties and Defects: Warranty period, defects liability, and rectification procedures
13. Insurance and Indemnity: Required insurance coverage and mutual indemnification provisions
14. Suspension and Termination: Grounds and procedures for suspension or termination of works
15. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration
16. General Provisions: Standard clauses including notices, governing law, entire agreement, and assignment
17. Signatures: Execution clause and signature blocks for all parties
1. Environmental Management: Required when project has significant environmental impact or requires environmental permits
2. Community Engagement: Needed for projects in residential areas or requiring community consultation
3. Broad-Based Black Economic Empowerment: Required for public sector projects or when specific BEE requirements apply
4. Performance Security: Include when contractor must provide performance bonds or guarantees
5. Intellectual Property: Required when design elements or proprietary methods are involved
6. Subcontracting: Include when subcontractors will be engaged for significant portions of work
7. Force Majeure: Detailed force majeure provisions for high-risk or long-term projects
8. Materials Storage and Security: Required for projects with significant materials storage requirements or security concerns
1. Schedule A - Scope of Works: Detailed technical specifications, drawings, and work requirements
2. Schedule B - Bill of Quantities: Itemized list of quantities and rates for all work elements
3. Schedule C - Project Timeline: Detailed project program including all milestones and critical paths
4. Schedule D - Payment Schedule: Detailed breakdown of payment terms, including milestone payments
5. Schedule E - Site Information: Site layout, access points, existing services, and site conditions
6. Schedule F - Health and Safety Requirements: Detailed safety specifications and procedures
7. Schedule G - Quality Assurance Plan: Quality control procedures and acceptance criteria
8. Schedule H - Insurance Requirements: Detailed insurance specifications and certificates
9. Appendix 1 - Required Permits and Licenses: List of all required regulatory approvals and their status
10. Appendix 2 - Key Personnel: List of key staff from both parties with roles and contact details
Find the exact document you need
Service Delivery Agreement Contract
A South African law-governed agreement defining the terms and conditions for service delivery between a provider and client, including service specifications, obligations, and performance standards.
Download
Terms And Agreement Contract
A South African law-compliant agreement establishing terms and conditions between parties in a business relationship.
Download
Generic Subcontractor Agreement
A South African law-governed agreement establishing terms between a main contractor and subcontractor for specified services or works.
Download
General Construction Contract Form
A South African construction agreement defining terms, conditions, and responsibilities between employer and contractor for building projects.
Download
Contract Between Employer And Contractor
A South African law-compliant agreement establishing terms and conditions between an employer and contractor, defining scope, payments, and obligations.
Download
Contract For Work For Hire
South African work for hire agreement establishing terms between a hiring entity and contractor, including IP rights transfer and deliverables.
Download
Labor Contract For (Construction)
South African construction industry employment contract template compliant with local labor laws and construction regulations.
Download
Independent Agreement
A South African law-governed agreement establishing the terms and conditions between a company and an independent contractor, ensuring clear distinction from employment relationships.
Download
Freelance Independent Contractor Agreement
A South African law-governed agreement establishing terms and conditions between a client and an independent contractor, defining services, payments, and relationship parameters.
Download
Contract Between Company And Contractor
A South African law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining services, payments, and operational parameters.
Download
Standard Renovation Contract
A comprehensive renovation agreement for South African construction projects, ensuring compliance with local building regulations and consumer protection laws.
Download
Agreement Between Owner And Electrical Contractor
A South African law-governed agreement between property owners and electrical contractors for electrical works, ensuring regulatory compliance and defining project terms.
Download
Contractor Lease Agreement
A South African law-governed agreement establishing terms for contractor property leasing, combining standard lease provisions with contractor-specific requirements.
Download
Labour Subcontractor Agreement
South African agreement regulating the provision of labour services between a main contractor and subcontractor, ensuring compliance with local labour laws.
Download
Agreement Construction Work
A South African law-governed agreement establishing terms and conditions between an employer and contractor for construction works, ensuring compliance with local construction regulations and industry standards.
Download
Hairdresser Independent Contractor Agreement
A South African law-governed agreement establishing an independent contractor relationship between a hairdresser and salon owner, outlining service terms and revenue sharing arrangements.
Download
Service Of Work Contract
A legally-binding agreement governed by South African law that establishes terms and conditions for service provision between a service provider and client.
Download
Payment Agreement Contract
A South African law-compliant contract that establishes formal payment terms and obligations between parties, including payment schedules, interest rates, and enforcement mechanisms.
Download
Independent Service Contract
A South African law-governed Independent Service Contract establishing terms between an independent contractor and client company, ensuring legal compliance while maintaining operational flexibility.
Download
Agreement Between Company And Labour Contractor
South African agreement governing the relationship between a company and labor contractor, ensuring compliance with local labor laws and regulations.
Download
Home Painting Contract
A South African-compliant contract governing residential painting services between homeowners and contractors.
Download
Contract For Builder And Client
A South African construction agreement that governs the relationship between builder and client, outlining construction terms, obligations, and compliance requirements.
Download
Subcontractor Employment Agreement
A South African law-governed agreement establishing terms and conditions between a company and subcontractor, defining service scope, payments, and mutual obligations.
Download
Painting Contract Agreement
A South African law-governed agreement between a painting contractor and client establishing terms for painting services, including scope, payment, and quality standards.
Download
Driver Contractor Agreement
A South African law-governed agreement establishing terms between a company and an independent driver contractor, covering operational, compliance, and compensation terms.
Download
Domestic Subcontract Agreement
A South African law-governed agreement between main contractor and subcontractor for domestic construction works, ensuring regulatory compliance and project delivery standards.
Download
Contractor Service Agreement
South African agreement establishing terms and conditions between a client and independent contractor, governed by SA law.
Download
Contractor Referral Agreement
A South African law-governed agreement establishing terms and conditions for contractor referrals between a referrer and recipient company, including referral fees and compliance requirements.
Download
Contract For Personal Service
A South African legal agreement establishing terms for independent personal services, distinguishing contractor relationships from employment.
Download
Contract For Labor Agreement
South African employment agreement establishing terms and conditions of employment in compliance with local labor laws.
Download
Consulting Agreement Contract
A South African law-governed agreement establishing terms and conditions between a client and consultant for professional consulting services.
Download
Construction Contractor Contract
A South African law-governed agreement between an employer and contractor for construction works, incorporating local construction industry regulations and standards.
Download
Standard Form Of Contract For Maintenance And Renovation Works
A standardized contract template for maintenance and renovation works in South Africa, incorporating local construction laws and industry requirements.
Download
Short Form Subcontractor Agreement
A concise legal agreement under South African law governing the relationship between a main contractor and subcontractor for project works.
Download
Self Employed Cleaner Contract
A South African law-governed contract establishing terms and conditions between a client and an independent cleaning contractor, defining service scope and contractor status.
Download
Sales Subcontractor Agreement
South African-governed agreement establishing terms for independent sales subcontractors, including commission structures and performance requirements.
Download
Prime Contractor Agreement
South African-governed agreement between an employer and prime contractor for construction projects, incorporating local regulatory requirements and industry standards.
Download
Preferred Contractor Agreement
A South African law-governed agreement establishing a preferential business relationship between a company and an independent contractor, defining service terms and maintaining contractor independence.
Download
Percentage Agreement Contract
A South African law-governed agreement establishing percentage-based payment terms and obligations between parties, including calculation methods and compliance requirements.
Download
Painting Subcontractor Contract
A South African law-governed agreement between a main contractor and painting subcontractor for professional painting services in construction projects.
Download
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it