The Standard General Contractor Contract is a fundamental document used in the Indian construction industry to establish a legally binding agreement between project owners and general contractors. This contract type is essential for projects requiring professional construction services and is structured to comply with Indian contract law, construction regulations, and industry standards. It encompasses crucial elements such as scope definition, pricing, timelines, quality requirements, and risk allocation, while ensuring adherence to local building codes, labor laws, and safety regulations. The document is particularly relevant for medium to large-scale construction projects where professional project management and formal contractual relationships are required. It provides a comprehensive framework for project execution, including mechanisms for changes, dispute resolution, and project completion, while protecting the interests of all parties involved.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification of the Owner/Employer and the General Contractor, including their legal details and registered addresses
2. Background: Context of the agreement, brief project overview, and basis for entering into the contract
3. Definitions: Detailed definitions of terms used throughout the contract
4. Scope of Work: Detailed description of the construction work to be performed by the General Contractor
5. Contract Price and Payment Terms: Total contract value, payment schedule, milestone payments, and payment procedures
6. Project Timeline: Commencement date, completion date, project phases, and milestone deadlines
7. Contractor's Obligations: General Contractor's responsibilities, including quality standards, labor, materials, and supervision
8. Owner's Obligations: Owner's responsibilities including site access, approvals, and permits
9. Quality Standards: Required quality standards, inspections, and acceptance criteria
10. Safety Requirements: Safety protocols, compliance with laws, and accident prevention measures
11. Changes and Variations: Procedures for handling changes to scope, pricing, or timeline
12. Insurance and Indemnity: Required insurance coverage and indemnification obligations
13. Default and Termination: Events of default, remedies, and termination procedures
14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
15. Force Majeure: Provisions for handling unforeseen circumstances and their impact
16. Governing Law: Specification of Indian law as governing law and jurisdiction
17. Notices: Process and addresses for serving formal notices
18. General Provisions: Standard boilerplate clauses including assignment, waiver, and severability
1. Subcontracting: Rules and procedures for subcontracting work - include when subcontractors are expected to be used
2. Environmental Compliance: Specific environmental obligations - include for projects with significant environmental impact
3. Labor Compliance: Detailed labor law compliance requirements - include for large projects with significant workforce
4. Intellectual Property Rights: IP ownership and licenses - include when design or technical innovations are involved
5. Performance Security: Requirements for performance bonds or guarantees - include for high-value projects
6. Warranty Period: Extended warranty terms - include for complex construction projects
7. Site Conditions: Specific site-related obligations and risks - include for projects with challenging site conditions
8. Materials Storage: Requirements for storage and security of materials - include for projects with significant material requirements
1. Schedule A - Scope of Work: Detailed technical specifications and drawings of the project
2. Schedule B - Bill of Quantities: Detailed breakdown of quantities and rates for all work items
3. Schedule C - Project Timeline: Detailed project schedule with milestones and critical path
4. Schedule D - Payment Schedule: Detailed payment terms, milestone payments, and payment procedures
5. Schedule E - Quality Standards: Specific quality requirements, testing procedures, and acceptance criteria
6. Schedule F - Site Details: Site plan, access points, and site-specific requirements
7. Schedule G - List of Approved Subcontractors: Pre-approved subcontractors for specific work packages
8. Schedule H - Forms and Certificates: Standard forms for variations, completion certificates, and other project documents
9. Schedule I - Insurance Requirements: Detailed insurance coverage requirements and minimum values
10. Schedule J - Safety Requirements: Specific safety protocols and procedures
Relevant legal definitions
Agreement
Applicable Laws
Approved
Architect
As-Built Drawings
Bill of Quantities
Certificate of Completion
Change Order
Commencement Date
Completion Date
Confidential Information
Construction Documents
Construction Equipment
Construction Schedule
Contract Price
Contractor
Contractor's Documents
Day
Defects
Defects Liability Period
Deliverables
Drawings
Effective Date
Employer
Extension of Time
Final Completion
Force Majeure Event
Good Industry Practice
Governmental Authority
Intellectual Property Rights
Labour
Materials
Milestone
Notice
Owner
Payment Certificate
Performance Security
Permits
Project
Project Manager
Project Site
Quality Assurance
Retention Money
Safety Requirements
Schedule of Rates
Scope of Work
Specifications
Subcontractor
Substantial Completion
Temporary Works
Time for Completion
Variation
Work
Working Day
Applicable Laws
Approved
Architect
As-Built Drawings
Bill of Quantities
Certificate of Completion
Change Order
Commencement Date
Completion Date
Confidential Information
Construction Documents
Construction Equipment
Construction Schedule
Contract Price
Contractor
Contractor's Documents
Day
Defects
Defects Liability Period
Deliverables
Drawings
Effective Date
Employer
Extension of Time
Final Completion
Force Majeure Event
Good Industry Practice
Governmental Authority
Intellectual Property Rights
Labour
Materials
Milestone
Notice
Owner
Payment Certificate
Performance Security
Permits
Project
Project Manager
Project Site
Quality Assurance
Retention Money
Safety Requirements
Schedule of Rates
Scope of Work
Specifications
Subcontractor
Substantial Completion
Temporary Works
Time for Completion
Variation
Work
Working Day
Clauses
Interpretation
Scope of Work
Contract Price
Payment Terms
Project Timeline
Performance Obligations
Quality Control
Health and Safety
Environmental Compliance
Labor Compliance
Materials and Equipment
Site Access and Conditions
Variations
Extensions of Time
Force Majeure
Insurance
Indemnification
Warranties
Defects Liability
Subcontracting
Assignment
Confidentiality
Intellectual Property
Performance Security
Retention
Testing and Inspection
Completion and Handover
Termination
Default
Suspension
Dispute Resolution
Governing Law
Notices
Limitations of Liability
Risk Allocation
Representations and Warranties
Documentation
Compliance with Laws
Reports and Records
Permits and Licenses
Security
Working Hours
Site Management
Storage and Protection
Utilities
Boilerplate Clauses
Scope of Work
Contract Price
Payment Terms
Project Timeline
Performance Obligations
Quality Control
Health and Safety
Environmental Compliance
Labor Compliance
Materials and Equipment
Site Access and Conditions
Variations
Extensions of Time
Force Majeure
Insurance
Indemnification
Warranties
Defects Liability
Subcontracting
Assignment
Confidentiality
Intellectual Property
Performance Security
Retention
Testing and Inspection
Completion and Handover
Termination
Default
Suspension
Dispute Resolution
Governing Law
Notices
Limitations of Liability
Risk Allocation
Representations and Warranties
Documentation
Compliance with Laws
Reports and Records
Permits and Licenses
Security
Working Hours
Site Management
Storage and Protection
Utilities
Boilerplate Clauses
Relevant Industries
Commercial Construction
Residential Construction
Industrial Construction
Infrastructure Development
Real Estate Development
Government Construction
Healthcare Construction
Educational Facilities
Retail Construction
Hospitality Construction
Manufacturing Facilities
Transportation Infrastructure
Relevant Teams
Legal
Operations
Construction
Project Management
Commercial
Procurement
Finance
Risk Management
Quality Control
Health and Safety
Technical Services
Business Development
Contract Administration
Relevant Roles
Project Manager
Construction Manager
Contract Administrator
Legal Counsel
Quantity Surveyor
Site Supervisor
Procurement Manager
Chief Engineer
Operations Director
Risk Manager
Commercial Manager
Business Development Manager
Managing Director
CEO
CFO
Technical Director
Quality Control Manager
Health and Safety Manager
Find the exact document you need
Material Supply Contract In (Construction)
An Indian law-governed agreement establishing terms for construction material supply, including specifications, quality standards, delivery terms, and regulatory compliance requirements.
find out more
Land Owner Builder Agreement
An Indian law-governed agreement between landowner and builder/developer establishing terms for property development and construction.
find out more
Labor Contract For (Construction)
An Indian-law compliant labor contract for construction workers, establishing employment terms and conditions while ensuring compliance with Indian construction industry regulations.
find out more
Joint Development Agreement For (Construction)
An Indian law-governed agreement establishing terms between landowner and developer for joint construction project development, including rights, obligations, and profit-sharing arrangements.
find out more
Home Renovation Contractor Agreement
An Indian law-governed agreement between property owners and contractors for home renovation projects, detailing work scope, terms, and obligations.
find out more
Cost Plus Residential Construction Contract
An Indian law-governed construction contract establishing cost-plus pricing terms for residential building projects, with contractor compensation based on actual costs plus agreed markup.
find out more
Contractor Agreement For House (Construction)
An Indian law-governed agreement between property owner and contractor for house construction, detailing construction terms, specifications, and compliance requirements.
find out more
Building Contract And Consultancy Agreement For A Home Owner Occupier
An Indian law-governed agreement between a home owner-occupier and construction/consultancy providers for residential property construction and related services.
find out more
Third Party Agreement (Construction)
An Indian law-governed agreement between principal contractor and subcontractor for construction works, establishing their rights and obligations.
find out more
Tripartite Agreement In (Construction)
An Indian law-governed agreement establishing rights and obligations between three parties in a construction project, typically involving developer, contractor, and financier/buyer.
find out more
Standard General Contractor Contract
An Indian law-governed construction agreement between project owner and general contractor defining terms, obligations, and requirements for construction project execution.
find out more
Residential Construction Management Agreement
An Indian law-compliant agreement between property owner and construction manager for managing residential construction projects, incorporating RERA and local building regulations.
find out more
Simple Works Contract
An Indian law-governed contract between an employer and contractor for executing specified construction or physical works, incorporating essential legal and practical requirements.
find out more
Project Management Contract In (Construction)
A Project Management Contract for construction projects in India, establishing terms for project management services under Indian law.
find out more
Project Management Agreement (Construction)
An Indian law-governed agreement defining terms for professional project management services in construction projects, including scope, responsibilities, and compliance requirements.
find out more
Joint Venture Agreement For (Construction)
An Indian law-governed agreement establishing a joint venture between parties for construction projects, detailing operational, financial, and management arrangements.
find out more
Independent Contractor Agreement For (Construction)
An Indian law-compliant agreement governing the relationship between a hiring entity and an independent contractor for construction services.
find out more
Generic Construction Contract
Standard construction contract template compliant with Indian law, suitable for various construction projects in India.
find out more
Construction Payment Agreement
An Indian law-governed agreement establishing payment terms and procedures for construction projects, including payment milestones, documentation requirements, and dispute resolution mechanisms.
find out more
Construction Agreement And Sale Agreement
An Indian law-governed agreement combining construction specifications and property sale terms, compliant with RERA and related legislation.
find out more
Contract Between Contractor And Owner
An Indian law-governed agreement between property owner and construction contractor defining construction terms, obligations, and project execution requirements.
find out more
Standard Contractor Contract
An Indian law-governed agreement establishing and regulating the relationship between a company and an independent contractor, defining key terms and obligations.
find out more
Simple Contract Agreement For Construction Work
A standard construction agreement under Indian law defining terms between client and contractor for construction works.
find out more
Construction Agreement Letter
An Indian jurisdiction document establishing terms between property owner/developer and contractor for construction projects, governed by Indian contract law.
find out more
Standard Building Contract
An Indian law-governed agreement between property owners/developers and contractors establishing terms for construction projects.
find out more
Real Estate Construction Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction services, including scope, payments, and regulatory compliance.
find out more
Construction Warranty Agreement
An Indian law-governed agreement establishing construction warranty terms between builders and property owners, detailing coverage, claims procedures, and remedies for construction defects.
find out more
Contract Between Builder And Subcontractor
An Indian law-governed agreement between a builder and subcontractor for construction works, detailing scope, terms, and compliance requirements.
find out more
Construction Completion Agreement
An Indian law-governed agreement that establishes terms and conditions for completing an ongoing construction project, ensuring compliance with local construction regulations and RERA.
find out more
Residential Construction Management Contract
An Indian law-compliant agreement for managing residential construction projects, establishing terms between property owners and construction managers.
find out more
Simple Work For Hire Agreement
An Indian law-governed agreement establishing a work-for-hire relationship between a client and contractor, defining work scope and IP rights transfer.
find out more
Agreement Between Builder And Contractor
An Indian law-governed agreement between builder and contractor defining construction project terms, obligations, and deliverables.
find out more
Landscape Contractor Contract
An Indian law-governed contract between a client and landscape contractor establishing terms for landscaping works, including scope, payments, and compliance requirements.
find out more
Contract Between Builder And Client
An Indian law-governed construction agreement between a builder and client, outlining project terms, specifications, and mutual obligations.
find out more
Agreement Between Two Contractors
An Indian law-governed agreement establishing terms and conditions between two independent contractors for professional collaboration and service delivery.
find out more
Swimming Pool Construction Agreement
An Indian law-governed agreement for swimming pool construction, detailing contractor and owner obligations, specifications, and compliance requirements.
find out more
Standard Construction Agreement
An Indian law-governed agreement between owner and contractor establishing terms and conditions for construction projects.
find out more
Owner Builder Subcontractor Agreement
An Indian law-compliant agreement between an owner-builder and subcontractor for construction works, detailing work scope, payments, and compliance requirements.
find out more
Construction Labor Contract Agreement
An Indian law-governed agreement establishing terms for construction labor supply and management, ensuring compliance with relevant labor laws and regulations.
find out more
Construction Collaboration Agreement
An agreement governing construction collaboration between multiple parties in India, outlining project terms, responsibilities, and compliance with Indian construction laws.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)