The Construction Subcontract is essential for projects where a main contractor needs to delegate specific portions of construction work to specialized subcontractors. This document type is commonly used in Indian construction projects across various scales, from residential developments to major infrastructure works. It ensures compliance with Indian construction laws, including the Building and Other Construction Workers Act, labor laws, and relevant state regulations. The agreement typically includes detailed specifications of work scope, quality standards, safety requirements, and payment terms. It protects both parties' interests while ensuring project delivery meets the main contract's requirements. This document is particularly important given India's complex regulatory environment and the need for clear delineation of responsibilities in construction projects.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification of the main contractor and subcontractor with complete legal details
2. Background: Context of the main contract and the need for subcontracting specific works
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Work: Detailed description of the works to be performed by the subcontractor
5. Contract Price and Payment Terms: Amount payable, payment schedule, retention money, and payment conditions
6. Timeline and Completion: Project schedule, milestones, completion dates, and delay consequences
7. Subcontractor's Obligations: Key responsibilities including labor, materials, equipment, and compliance requirements
8. Main Contractor's Obligations: Responsibilities of the main contractor including site access and information provision
9. Quality Standards: Required quality standards, inspections, and approval processes
10. Health and Safety: Safety requirements, compliance with regulations, and accident prevention measures
11. Insurance and Indemnity: Required insurance coverage and indemnification obligations
12. Warranties: Warranties for workmanship, materials, and defect liability period
13. Variations: Process for handling changes to scope, pricing, or timeline
14. Termination: Grounds and process for contract termination
15. Dispute Resolution: Process for resolving disputes including mediation and arbitration
16. Governing Law: Specification of Indian law as governing law and jurisdiction
1. Performance Security: Requirements for performance bank guarantee when required by main contract or project value
2. Mobilization Advance: Terms for advance payment if applicable to the project
3. Environmental Compliance: Specific environmental requirements for projects with significant environmental impact
4. Intellectual Property Rights: IP provisions when design or innovative construction methods are involved
5. Force Majeure: Provisions for unforeseen circumstances affecting contract performance
6. Confidentiality: Confidentiality obligations when dealing with sensitive project information
7. Step-in Rights: Main contractor's right to take over subcontractor's work in specific circumstances
8. Local Content Requirements: Provisions for local material or labor requirements if specified by project or law
1. Schedule A - Scope of Work: Detailed technical specifications and drawings of the works
2. Schedule B - Bill of Quantities: Itemized list of works with quantities and rates
3. Schedule C - Payment Schedule: Detailed breakdown of payment milestones and amounts
4. Schedule D - Project Timeline: Detailed project schedule with milestones and completion dates
5. Schedule E - Quality Assurance Plan: Detailed quality standards and testing requirements
6. Schedule F - HSE Requirements: Detailed health, safety, and environmental requirements
7. Schedule G - Forms and Certificates: Standard forms for communications, approvals, and certificates
8. Schedule H - Insurance Requirements: Detailed insurance coverage requirements and limits
9. Appendix 1 - Site Rules: Specific rules and regulations for working on the project site
10. Appendix 2 - Technical Drawings: Complete set of technical and construction drawings
Relevant legal definitions
Agreement
Applicable Laws
Approved
As-Built Drawings
Bill of Quantities
Completion Certificate
Contract Price
Day
Defects Liability Period
Drawings
Equipment
Extension of Time
Force Majeure Event
Good Industry Practice
HSE Requirements
Main Contract
Main Contractor
Materials
Method Statement
Milestone
Notice
Owner
Payment Certificate
Performance Security
Project
Project Manager
Project Schedule
Quality Assurance Plan
Retention Money
Site
Specifications
Subcontractor
Substantial Completion
Technical Documents
Variation
Variation Order
Work Order
Works
Working Day
Applicable Laws
Approved
As-Built Drawings
Bill of Quantities
Completion Certificate
Contract Price
Day
Defects Liability Period
Drawings
Equipment
Extension of Time
Force Majeure Event
Good Industry Practice
HSE Requirements
Main Contract
Main Contractor
Materials
Method Statement
Milestone
Notice
Owner
Payment Certificate
Performance Security
Project
Project Manager
Project Schedule
Quality Assurance Plan
Retention Money
Site
Specifications
Subcontractor
Substantial Completion
Technical Documents
Variation
Variation Order
Work Order
Works
Working Day
Clauses
Interpretation
Scope of Work
Contract Price
Payment Terms
Project Timeline
Variations
Quality Control
Materials and Workmanship
Health and Safety
Environmental Compliance
Labor Laws Compliance
Insurance
Indemnification
Performance Security
Warranties
Site Access
Equipment and Tools
Subcontractor Obligations
Main Contractor Obligations
Progress Reporting
Testing and Inspection
Completion and Handover
Defects Liability
Force Majeure
Suspension
Termination
Dispute Resolution
Governing Law
Notices
Assignment
Confidentiality
Record Keeping
Intellectual Property
Compliance with Laws
Anti-corruption
Severability
Entire Agreement
Scope of Work
Contract Price
Payment Terms
Project Timeline
Variations
Quality Control
Materials and Workmanship
Health and Safety
Environmental Compliance
Labor Laws Compliance
Insurance
Indemnification
Performance Security
Warranties
Site Access
Equipment and Tools
Subcontractor Obligations
Main Contractor Obligations
Progress Reporting
Testing and Inspection
Completion and Handover
Defects Liability
Force Majeure
Suspension
Termination
Dispute Resolution
Governing Law
Notices
Assignment
Confidentiality
Record Keeping
Intellectual Property
Compliance with Laws
Anti-corruption
Severability
Entire Agreement
Relevant Industries
Construction
Real Estate Development
Infrastructure
Industrial Construction
Commercial Construction
Residential Construction
Mining
Energy
Transportation
Healthcare
Education
Hospitality
Retail
Relevant Teams
Legal
Operations
Procurement
Project Management
Construction
Commercial
Risk & Compliance
Health Safety & Environment
Finance
Technical Services
Quality Assurance
Relevant Roles
Project Manager
Construction Manager
Contract Manager
Legal Counsel
Procurement Manager
Site Supervisor
Chief Engineer
Operations Director
Risk Manager
Compliance Officer
Quantity Surveyor
Commercial Manager
HSE Manager
Finance Manager
Technical Director
Find the exact document you need
Material Supply Contract In (Construction)
An Indian law-governed agreement establishing terms for construction material supply, including specifications, quality standards, delivery terms, and regulatory compliance requirements.
find out more
Land Owner Builder Agreement
An Indian law-governed agreement between landowner and builder/developer establishing terms for property development and construction.
find out more
Labor Contract For (Construction)
An Indian-law compliant labor contract for construction workers, establishing employment terms and conditions while ensuring compliance with Indian construction industry regulations.
find out more
Joint Development Agreement For (Construction)
An Indian law-governed agreement establishing terms between landowner and developer for joint construction project development, including rights, obligations, and profit-sharing arrangements.
find out more
Home Renovation Contractor Agreement
An Indian law-governed agreement between property owners and contractors for home renovation projects, detailing work scope, terms, and obligations.
find out more
Cost Plus Residential Construction Contract
An Indian law-governed construction contract establishing cost-plus pricing terms for residential building projects, with contractor compensation based on actual costs plus agreed markup.
find out more
Contractor Agreement For House (Construction)
An Indian law-governed agreement between property owner and contractor for house construction, detailing construction terms, specifications, and compliance requirements.
find out more
Building Contract And Consultancy Agreement For A Home Owner Occupier
An Indian law-governed agreement between a home owner-occupier and construction/consultancy providers for residential property construction and related services.
find out more
Third Party Agreement (Construction)
An Indian law-governed agreement between principal contractor and subcontractor for construction works, establishing their rights and obligations.
find out more
Tripartite Agreement In (Construction)
An Indian law-governed agreement establishing rights and obligations between three parties in a construction project, typically involving developer, contractor, and financier/buyer.
find out more
Standard General Contractor Contract
An Indian law-governed construction agreement between project owner and general contractor defining terms, obligations, and requirements for construction project execution.
find out more
Residential Construction Management Agreement
An Indian law-compliant agreement between property owner and construction manager for managing residential construction projects, incorporating RERA and local building regulations.
find out more
Simple Works Contract
An Indian law-governed contract between an employer and contractor for executing specified construction or physical works, incorporating essential legal and practical requirements.
find out more
Project Management Contract In (Construction)
A Project Management Contract for construction projects in India, establishing terms for project management services under Indian law.
find out more
Project Management Agreement (Construction)
An Indian law-governed agreement defining terms for professional project management services in construction projects, including scope, responsibilities, and compliance requirements.
find out more
Joint Venture Agreement For (Construction)
An Indian law-governed agreement establishing a joint venture between parties for construction projects, detailing operational, financial, and management arrangements.
find out more
Independent Contractor Agreement For (Construction)
An Indian law-compliant agreement governing the relationship between a hiring entity and an independent contractor for construction services.
find out more
Generic Construction Contract
Standard construction contract template compliant with Indian law, suitable for various construction projects in India.
find out more
Construction Payment Agreement
An Indian law-governed agreement establishing payment terms and procedures for construction projects, including payment milestones, documentation requirements, and dispute resolution mechanisms.
find out more
Construction Agreement And Sale Agreement
An Indian law-governed agreement combining construction specifications and property sale terms, compliant with RERA and related legislation.
find out more
Contract Between Contractor And Owner
An Indian law-governed agreement between property owner and construction contractor defining construction terms, obligations, and project execution requirements.
find out more
Standard Contractor Contract
An Indian law-governed agreement establishing and regulating the relationship between a company and an independent contractor, defining key terms and obligations.
find out more
Simple Contract Agreement For Construction Work
A standard construction agreement under Indian law defining terms between client and contractor for construction works.
find out more
Construction Agreement Letter
An Indian jurisdiction document establishing terms between property owner/developer and contractor for construction projects, governed by Indian contract law.
find out more
Standard Building Contract
An Indian law-governed agreement between property owners/developers and contractors establishing terms for construction projects.
find out more
Real Estate Construction Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction services, including scope, payments, and regulatory compliance.
find out more
Construction Warranty Agreement
An Indian law-governed agreement establishing construction warranty terms between builders and property owners, detailing coverage, claims procedures, and remedies for construction defects.
find out more
Contract Between Builder And Subcontractor
An Indian law-governed agreement between a builder and subcontractor for construction works, detailing scope, terms, and compliance requirements.
find out more
Construction Completion Agreement
An Indian law-governed agreement that establishes terms and conditions for completing an ongoing construction project, ensuring compliance with local construction regulations and RERA.
find out more
Residential Construction Management Contract
An Indian law-compliant agreement for managing residential construction projects, establishing terms between property owners and construction managers.
find out more
Simple Work For Hire Agreement
An Indian law-governed agreement establishing a work-for-hire relationship between a client and contractor, defining work scope and IP rights transfer.
find out more
Agreement Between Builder And Contractor
An Indian law-governed agreement between builder and contractor defining construction project terms, obligations, and deliverables.
find out more
Landscape Contractor Contract
An Indian law-governed contract between a client and landscape contractor establishing terms for landscaping works, including scope, payments, and compliance requirements.
find out more
Contract Between Builder And Client
An Indian law-governed construction agreement between a builder and client, outlining project terms, specifications, and mutual obligations.
find out more
Agreement Between Two Contractors
An Indian law-governed agreement establishing terms and conditions between two independent contractors for professional collaboration and service delivery.
find out more
Swimming Pool Construction Agreement
An Indian law-governed agreement for swimming pool construction, detailing contractor and owner obligations, specifications, and compliance requirements.
find out more
Standard Construction Agreement
An Indian law-governed agreement between owner and contractor establishing terms and conditions for construction projects.
find out more
Owner Builder Subcontractor Agreement
An Indian law-compliant agreement between an owner-builder and subcontractor for construction works, detailing work scope, payments, and compliance requirements.
find out more
Construction Labor Contract Agreement
An Indian law-governed agreement establishing terms for construction labor supply and management, ensuring compliance with relevant labor laws and regulations.
find out more
Construction Collaboration Agreement
An agreement governing construction collaboration between multiple parties in India, outlining project terms, responsibilities, and compliance with Indian construction laws.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)