The Construction Work Agreement is a vital legal document used in Malta for establishing the contractual relationship between parties involved in construction projects. It is essential for any construction undertaking, whether commercial, residential, or industrial, and must comply with Malta's robust regulatory framework, including the Building Regulation Act and recent construction industry reforms. This agreement type is specifically designed to address the unique aspects of construction projects in Malta, including local building standards, planning requirements, and safety regulations. The document typically includes comprehensive details about the construction project, from technical specifications to payment terms, and incorporates necessary provisions to protect all parties' interests while ensuring compliance with Maltese construction law and EU standards. It's particularly important given Malta's specific construction requirements and recent regulatory changes aimed at improving building and construction standards.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification of the Employer and the Contractor, including full legal names, registration numbers, and registered addresses
2. Background: Context of the agreement, including project overview and basis for entering into the contract
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Works: Detailed description of the construction works to be performed
5. Contract Price and Payment Terms: Amount payable, payment schedule, retention amounts, and payment conditions
6. Duration and Timeline: Project commencement date, completion date, and key milestones
7. Contractor Obligations: Key responsibilities and obligations of the contractor including quality standards and compliance requirements
8. Employer Obligations: Key responsibilities and obligations of the employer including site access and necessary permits
9. Materials and Equipment: Requirements for construction materials, equipment, and their procurement
10. Health and Safety: Safety requirements and compliance with Maltese health and safety regulations
11. Insurance and Indemnities: Required insurance coverage and indemnification provisions
12. Variations and Changes: Process for handling changes to the scope of work and cost implications
13. Defects and Warranties: Defects liability period and warranty provisions
14. Termination: Grounds and process for contract termination by either party
15. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
16. Governing Law: Confirmation of Maltese law as governing law and jurisdiction
17. General Provisions: Standard boilerplate clauses including notices, entire agreement, and severability
1. Performance Bond: Required when a performance guarantee is needed for the project
2. Environmental Compliance: Detailed environmental obligations for projects with significant environmental impact
3. Subcontracting: Terms for engaging and managing subcontractors, if permitted
4. Force Majeure: Provisions for handling unforeseen circumstances and their impact on the project
5. Intellectual Property: Required for projects involving design elements or proprietary methods
6. Site Security: Specific security requirements for high-security or sensitive locations
7. Utilities and Services: Provisions regarding temporary and permanent utility connections
8. Testing and Commissioning: Detailed requirements for projects requiring specific testing procedures
1. Schedule 1 - Works Specification: Detailed technical specifications of the construction works
2. Schedule 2 - Site Plans and Drawings: Architectural and engineering drawings, site plans, and design details
3. Schedule 3 - Bill of Quantities: Itemized list of materials, quantities, and costs
4. Schedule 4 - Project Timeline: Detailed project schedule with milestones and completion dates
5. Schedule 5 - Payment Schedule: Detailed breakdown of payment stages and amounts
6. Schedule 6 - Quality Standards: Specific quality requirements and applicable standards
7. Schedule 7 - Required Permits and Licenses: List of necessary permits and responsibilities for obtaining them
8. Schedule 8 - Insurance Requirements: Detailed insurance specifications and coverage requirements
9. Appendix A - Site Rules and Regulations: Specific rules governing conduct and operations on the construction site
10. Appendix B - Health and Safety Plan: Detailed health and safety procedures and requirements
Find the exact document you need
Project Based Contract Agreement
A Maltese law-governed agreement establishing terms and conditions for project-based work between client and contractor.
Download
Design Build Contract
A Maltese law-governed contract combining design and construction responsibilities under a single contractor's scope.
Download
Construction Work Agreement
A Maltese law-governed agreement setting out terms and conditions for construction works between an employer and contractor, including scope, payment, and compliance with local building regulations.
Download
Project Management Agreement
A Maltese law-governed agreement setting out terms for professional project management services, including scope, responsibilities, and commercial terms.
Download
Building Work Agreement
A Maltese law-governed agreement setting out terms and conditions for construction work between an employer and contractor, ensuring compliance with local building regulations and standards.
Download
Turnkey Contract Agreement
A Maltese law-governed agreement for the delivery of a complete, ready-to-use facility, covering design, construction, and commissioning under a single contractor's responsibility.
Download
Renovation Agreement
A Maltese law-governed agreement establishing terms and conditions for property renovation works, including scope, payments, and regulatory compliance.
Download
Demolition Agreement
A Maltese law-governed agreement setting out terms and conditions for demolition works, including regulatory compliance, safety measures, and contractor obligations.
Download
Consortium Agreement Between Companies
A Maltese law-governed agreement establishing and regulating a formal consortium between multiple companies, outlining their rights, obligations, and collaborative framework.
Download
General Construction Agreement
A Maltese law-governed agreement setting out terms and conditions for construction projects, including rights, obligations, and compliance with local building regulations.
Download
Proof Of Concept Agreement
A Maltese law-governed agreement establishing terms and conditions for conducting and evaluating a proof of concept between technology providers and clients.
Download
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)