The New Construction Agreement is a fundamental document used in Denmark for establishing the contractual relationship between a client/employer and a contractor for new building projects. It is designed to comply with Danish construction law, particularly AB 18 (General Conditions for Building and Construction Works), the Danish Building Act, and associated regulations. This agreement is essential when commissioning new construction works, whether for commercial, residential, or industrial purposes. It contains detailed provisions covering project scope, payment terms, completion timelines, quality standards, and risk allocation. The document includes references to technical specifications, drawings, and other crucial project documentation through its schedules and appendices. The agreement is structured to protect both parties' interests while ensuring compliance with Danish construction industry standards and practices.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
New Construction Agreement
I need a New Construction Agreement under Danish law for a commercial office building project in Copenhagen, with a contract value of 15 million EUR and completion date of June 2025, including specific provisions for sustainable building standards and LEED certification requirements.
1. Parties: Identification of the employer/client and the contractor, including full legal names, registration numbers, and addresses
2. Background: Context of the construction project, including the purpose and any relevant preliminary work or agreements
3. Definitions: Definitions of key terms used throughout the agreement
4. Scope of Works: Detailed description of the construction works to be performed, including reference to technical specifications
5. Contract Documents: Hierarchy and list of all documents forming part of the contract
6. Contract Sum: The agreed price for the works, including payment structure, milestones, and any provisions for price adjustments
7. Time for Completion: Project timeline, key milestone dates, and completion deadline
8. Contractor Obligations: Main responsibilities of the contractor, including quality standards, compliance with regulations, and supervision
9. Employer Obligations: Main responsibilities of the employer, including site access, permits, and information provision
10. Variations: Procedures for handling changes to the scope of works
11. Quality Assurance: Quality control procedures, inspections, and acceptance criteria
12. Health and Safety: Safety requirements and responsibilities in accordance with Danish regulations
13. Insurance and Liability: Required insurance coverage and allocation of risks
14. Defects Liability: Warranty period and procedures for handling defects
15. Force Majeure: Provisions for unforeseeable circumstances and their handling
16. Termination: Grounds and procedures for contract termination
17. Dispute Resolution: Procedures for handling disputes, including mediation and arbitration
18. Governing Law: Confirmation of Danish law as governing law and jurisdiction
1. Environmental Requirements: Specific environmental obligations and sustainability requirements, used for projects with particular environmental focus or certification requirements
2. Intellectual Property Rights: Provisions regarding design rights and other IP, used when the contractor is involved in design work
3. Bonds and Guarantees: Requirements for performance bonds or other financial securities, used for larger projects
4. Liquidated Damages: Specific compensation for delay or performance failures, used when particular milestone dates are critical
5. Subcontractors: Provisions regarding the appointment and management of subcontractors, used when subcontracting is anticipated
6. Building Information Modeling: BIM requirements and procedures, used for projects utilizing BIM technology
7. Archaeological Findings: Procedures for handling archaeological discoveries, used for projects in historically sensitive areas
8. Financing Arrangements: Details of project financing and related conditions, used when specific financing arrangements affect the contract
1. Technical Specifications: Detailed technical requirements and specifications for the works
2. Drawings: List and copies of all relevant construction drawings
3. Price Schedule: Detailed breakdown of the contract sum and payment schedule
4. Programme of Works: Detailed construction schedule with milestones
5. Site Information: Details about the construction site, including surveys and ground conditions
6. Quality Control Plan: Detailed procedures for quality assurance and control
7. Health and Safety Plan: Detailed safety procedures and requirements
8. Insurance Certificates: Copies of required insurance policies
9. Form of Bonds/Guarantees: Templates for required bonds or guarantees
10. List of Approved Subcontractors: Pre-approved subcontractors for specific works
11. Environmental Management Plan: Detailed environmental protection measures and procedures
Authors
Relevant legal definitions
Agreement
Applicable Laws
Architect
As-Built Drawings
Building Permit
Certificate of Completion
Change Order
Commencement Date
Completion Date
Construction Documents
Construction Period
Contract Sum
Contractor
Defects
Defects Liability Period
Delay Events
Design Documents
Drawings
Employer
Employer's Requirements
Extension of Time
Final Completion Certificate
Force Majeure Event
Good Industry Practice
Handover
Insurance Requirements
Intellectual Property Rights
Interim Payment Certificate
Key Personnel
Liquidated Damages
Material Breach
Milestone Dates
Notice
Payment Schedule
Performance Bond
Practical Completion
Programme of Works
Project
Project Manager
Quality Assurance Plan
Retention Money
Site
Specifications
Subcontractor
Substantial Completion
Technical Advisor
Time for Completion
Variation
Works
Working Day
Applicable Laws
Architect
As-Built Drawings
Building Permit
Certificate of Completion
Change Order
Commencement Date
Completion Date
Construction Documents
Construction Period
Contract Sum
Contractor
Defects
Defects Liability Period
Delay Events
Design Documents
Drawings
Employer
Employer's Requirements
Extension of Time
Final Completion Certificate
Force Majeure Event
Good Industry Practice
Handover
Insurance Requirements
Intellectual Property Rights
Interim Payment Certificate
Key Personnel
Liquidated Damages
Material Breach
Milestone Dates
Notice
Payment Schedule
Performance Bond
Practical Completion
Programme of Works
Project
Project Manager
Quality Assurance Plan
Retention Money
Site
Specifications
Subcontractor
Substantial Completion
Technical Advisor
Time for Completion
Variation
Works
Working Day
Clauses
Parties
Definitions
Interpretation
Contract Documents
Scope of Works
Contract Sum
Payment Terms
Time for Completion
Programme of Works
Site Access and Conditions
Contractor Obligations
Employer Obligations
Design Responsibilities
Materials and Workmanship
Quality Assurance
Testing and Inspection
Variations
Extensions of Time
Health and Safety
Environmental Protection
Insurance
Indemnification
Bonds and Guarantees
Intellectual Property
Confidentiality
Force Majeure
Suspension
Termination
Defects Liability
Warranties
Liquidated Damages
Risk Allocation
Subcontracting
Assignment and Novation
Notices
Dispute Resolution
Governing Law
Entire Agreement
Severability
Waiver
Third Party Rights
Definitions
Interpretation
Contract Documents
Scope of Works
Contract Sum
Payment Terms
Time for Completion
Programme of Works
Site Access and Conditions
Contractor Obligations
Employer Obligations
Design Responsibilities
Materials and Workmanship
Quality Assurance
Testing and Inspection
Variations
Extensions of Time
Health and Safety
Environmental Protection
Insurance
Indemnification
Bonds and Guarantees
Intellectual Property
Confidentiality
Force Majeure
Suspension
Termination
Defects Liability
Warranties
Liquidated Damages
Risk Allocation
Subcontracting
Assignment and Novation
Notices
Dispute Resolution
Governing Law
Entire Agreement
Severability
Waiver
Third Party Rights
Relevant Industries
Construction
Real Estate
Infrastructure
Commercial Property
Residential Property
Industrial
Healthcare
Education
Hospitality
Retail
Data Centers
Renewable Energy
Public Sector
Relevant Teams
Legal
Commercial
Construction
Operations
Finance
Procurement
Risk & Compliance
Technical
Business Development
Project Management
Health & Safety
Relevant Roles
Construction Manager
Project Director
Contract Manager
Legal Counsel
Commercial Director
Procurement Manager
Chief Financial Officer
Technical Director
Project Engineer
Risk Manager
Operations Director
Development Manager
Quantity Surveyor
Site Manager
Compliance Officer
Safety Manager
Business Development Manager
Bid Manager
Find the exact document you need
Construction Business Partnership Agreement
Danish law-governed agreement establishing a partnership between construction industry entities, defining terms, obligations, and operational framework.
find out more
Agreement With Builder For (Construction)
Danish law-governed construction agreement between building owner and contractor, establishing terms for construction project execution and compliance with Danish building regulations.
find out more
Vesting Agreement (Construction)
A legal agreement governing progressive ownership transfer during construction projects under Danish law.
find out more
Build Agreement
Danish law construction contract establishing terms and conditions between employer and contractor under AB 18 framework.
find out more
Novation Agreement (Construction)
A Danish law agreement transferring rights and obligations under a construction contract from an original contractor/consultant to a new one, ensuring project continuity under Danish construction regulations.
find out more
Turnkey Project Agreement
Danish law-governed agreement for complete turnkey project delivery, covering design through commissioning with contractor's full responsibility for operational facility delivery.
find out more
Residential Contractor Agreement
A Danish law-governed agreement between a contractor and homeowner for residential construction or renovation works, incorporating Danish construction and consumer protection requirements.
find out more
Mural Agreement
Danish law-governed agreement for commissioning and installing mural artwork, defining rights and responsibilities between artists and property owners.
find out more
Project Hire Contract
Danish law-governed agreement for project-based employment, defining project scope, deliverables, and employment terms.
find out more
Pipeline Agreement
Danish law-governed agreement for pipeline construction, operation, and maintenance, incorporating local regulatory requirements and EU compliance measures.
find out more
Consortium Partnership Agreement
Danish law-governed agreement establishing and regulating a consortium partnership between multiple organizations, defining collaboration terms and governance structure.
find out more
Building Construction Agreement
Danish law-governed construction agreement establishing terms between building owner and contractor, incorporating AB 18 principles and local building regulations.
find out more
Project Alliance Agreement
A Danish law-governed collaborative agreement establishing a project alliance framework for joint project delivery with shared risks and rewards.
find out more
Project Delivery Agreement
Danish law-governed agreement establishing terms and conditions for project delivery, including scope, deliverables, and party obligations.
find out more
Pilot Project Agreement
Danish law agreement for establishing and governing pilot projects, including scope, responsibilities, and IP rights.
find out more
Minor Works Agreement
A Danish law-governed construction contract for small-scale building projects and renovations, incorporating key principles from Danish construction law and the AB-System.
find out more
Turnkey Contract Agreement
A Danish law-governed agreement for turnkey construction projects, establishing comprehensive terms for design-build project delivery under ABT 18 principles.
find out more
Commercial Supply Agreement
A Danish law-governed agreement establishing terms and conditions for regular commercial supply of goods between supplier and buyer.
find out more
Engineering Procurement And Construction Agreement
Danish law-governed agreement for comprehensive engineering, procurement, and construction projects, detailing contractor obligations and project execution requirements.
find out more
Project Cooperation Agreement
Danish law-governed agreement establishing terms and conditions for multi-party project collaboration, including responsibilities, resources, and rights.
find out more
Project Agreement Contract
Danish law-governed agreement establishing terms and conditions for project execution, including scope, deliverables, timelines, and responsibilities.
find out more
New Construction Agreement
Danish law-governed agreement for new construction projects, incorporating AB 18 requirements and establishing key terms between client and contractor.
find out more
Renovation Agreement
Danish law-governed agreement outlining terms and conditions for property renovation work, including scope, pricing, timeline, and responsibilities.
find out more
Demolition Agreement
Danish law-governed agreement setting terms and conditions for demolition works, including safety, environmental, and regulatory requirements.
find out more
Project Development Agreement
A Danish law-governed agreement between developer and client establishing terms and conditions for property or infrastructure development projects.
find out more
Proof Of Concept Agreement
A Danish law agreement governing the testing and evaluation of new technologies or solutions, establishing terms for proof of concept implementation.
find out more
Pre Construction Agreement
Danish law-governed agreement establishing terms and conditions for pre-construction services between client and contractor.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our Trust Centre for more details and real-time security updates.
Read our Privacy Policy.