The Construction Management Contract is a specialized agreement used in Danish construction projects where professional construction management services are required to oversee and coordinate complex building projects. This document is essential when clients need expert management of their construction projects while maintaining direct contractual relationships with trade contractors. The contract, governed by Danish law and aligned with AB 18 and ABR 18 regulations, is particularly suitable for large-scale or complex projects requiring professional project coordination, cost control, and schedule management. It defines the Construction Manager's role in providing pre-construction services, construction phase management, and post-construction support, while establishing clear lines of responsibility and communication between all project stakeholders. The document includes comprehensive provisions for risk management, quality control, and project delivery, making it suitable for both public and private sector projects in Denmark.
Create a bespoke document in minutes, or upload and review your own.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Get your first 2 documents free
Your data doesn't train Genie's AI
You keep IP ownership of your information
Key Requirements PROMPT example:
Construction Management Contract
1. Parties: Identification of the Client/Employer and the Construction Manager, including full legal names, registration numbers, and addresses
2. Background: Context of the project, purpose of the agreement, and overview of the construction management arrangement
3. Definitions: Detailed definitions of key terms used throughout the contract, including technical and legal terminology
4. Scope of Services: Detailed description of the construction management services to be provided, including pre-construction, construction, and post-construction phases
5. Project Details: Specific information about the construction project, including location, type of building/structure, and key objectives
6. Construction Manager's Obligations: Comprehensive listing of the Construction Manager's duties, responsibilities, and standard of care
7. Client's Obligations: Client's responsibilities, including provision of information, approvals, and access to the site
8. Project Team and Personnel: Requirements for key personnel, subcontractors, and consultants, including qualification requirements and replacement procedures
9. Time Schedule: Project timeline, milestones, completion dates, and schedule management procedures
10. Fee Structure and Payment: Construction management fee calculation, payment schedule, and invoicing procedures
11. Changes and Variations: Procedures for handling changes to scope, schedule, or budget, including approval processes
12. Quality Management: Quality control procedures, standards, and compliance requirements
13. Risk Management: Risk allocation, insurance requirements, and mitigation strategies
14. Reporting and Documentation: Requirements for project reporting, record-keeping, and documentation
15. Termination: Grounds and procedures for contract termination, including consequences and obligations
16. Liability and Indemnification: Extent of liability, limitations, and indemnification obligations
17. Dispute Resolution: Procedures for handling disputes, including mediation and arbitration processes
18. General Provisions: Standard contract clauses including governing law, notices, and entire agreement provisions
1. Sustainable Construction Requirements: Special requirements for environmental sustainability and green building standards, included when project has specific sustainability goals
2. BIM Implementation: Requirements for Building Information Modeling, included when BIM is part of the project delivery method
3. Multiple Site Provisions: Special provisions for managing multiple construction sites, included for complex projects across multiple locations
4. Public Authority Interface: Special provisions for projects involving public authorities or requiring specific public approvals
5. Financing Requirements: Special provisions related to project financing arrangements, included when specific funding requirements exist
6. Value Engineering: Procedures for value engineering processes, included when cost optimization is a key project objective
7. Commissioning Requirements: Detailed commissioning procedures, included for complex technical installations
8. Phased Completion: Special provisions for projects requiring phased completion or partial handover
1. Schedule A - Scope of Services: Detailed breakdown of construction management services and deliverables
2. Schedule B - Fee Schedule: Detailed fee calculation, rates, and payment terms
3. Schedule C - Project Program: Detailed project timeline, milestones, and completion dates
4. Schedule D - Key Personnel: Details of key team members, their roles, and time commitment
5. Schedule E - Client's Requirements: Detailed technical and functional requirements for the project
6. Schedule F - Site Information: Site details, surveys, and existing condition reports
7. Schedule G - Quality Management Plan: Detailed quality control procedures and requirements
8. Schedule H - Reports and Documentation: Templates and requirements for project reporting
9. Schedule I - Insurance Requirements: Detailed insurance requirements and coverage limits
10. Schedule J - Forms and Procedures: Standard forms for changes, approvals, and other project procedures
11. Appendix 1 - Drawings and Specifications: Technical drawings and specifications
12. Appendix 2 - Permits and Approvals: Copies of relevant permits and regulatory approvals
Authors
Relevant legal definitions
Agreement
Applicable Laws
Approved
As-Built Documents
Authority Requirements
Base Date
Building Regulations
Certificate of Practical Completion
Change Order
Client
Client's Requirements
Commencement Date
Completion Date
Construction Documents
Construction Manager
Construction Phase
Construction Program
Construction Site
Contract Documents
Contract Sum
Contractor
Day
Defects
Defects Liability Period
Deliverables
Design Documents
Dispute
Drawings
Extension of Time
Fee
Force Majeure
Good Industry Practice
Governing Law
Health and Safety Plan
Insurance Requirements
Intellectual Property Rights
Key Personnel
Milestone
Notice
Parties
Payment Certificate
Performance Standards
Permits
Pre-Construction Phase
Project
Project Manager
Project Schedule
Quality Management Plan
Regulatory Requirements
Risk Register
Schedule of Services
Site
Specifications
Subcontractor
Substantial Completion
Technical Requirements
Time for Completion
Variation
Works
Applicable Laws
Approved
As-Built Documents
Authority Requirements
Base Date
Building Regulations
Certificate of Practical Completion
Change Order
Client
Client's Requirements
Commencement Date
Completion Date
Construction Documents
Construction Manager
Construction Phase
Construction Program
Construction Site
Contract Documents
Contract Sum
Contractor
Day
Defects
Defects Liability Period
Deliverables
Design Documents
Dispute
Drawings
Extension of Time
Fee
Force Majeure
Good Industry Practice
Governing Law
Health and Safety Plan
Insurance Requirements
Intellectual Property Rights
Key Personnel
Milestone
Notice
Parties
Payment Certificate
Performance Standards
Permits
Pre-Construction Phase
Project
Project Manager
Project Schedule
Quality Management Plan
Regulatory Requirements
Risk Register
Schedule of Services
Site
Specifications
Subcontractor
Substantial Completion
Technical Requirements
Time for Completion
Variation
Works
Clauses
Interpretation
Appointment
Duration
Construction Manager's Obligations
Client's Obligations
Project Management
Quality Control
Time Management
Cost Management
Risk Management
Health and Safety
Environmental Protection
Insurance
Indemnification
Warranties
Performance Standards
Personnel Requirements
Subcontracting
Documentation
Reporting
Communication
Variations
Payment
Intellectual Property
Confidentiality
Data Protection
Force Majeure
Suspension
Termination
Dispute Resolution
Limitation of Liability
Assignment
Notices
Governing Law
Entire Agreement
Appointment
Duration
Construction Manager's Obligations
Client's Obligations
Project Management
Quality Control
Time Management
Cost Management
Risk Management
Health and Safety
Environmental Protection
Insurance
Indemnification
Warranties
Performance Standards
Personnel Requirements
Subcontracting
Documentation
Reporting
Communication
Variations
Payment
Intellectual Property
Confidentiality
Data Protection
Force Majeure
Suspension
Termination
Dispute Resolution
Limitation of Liability
Assignment
Notices
Governing Law
Entire Agreement
Relevant Industries
Relevant Teams
Relevant Roles
Find the exact document you need
Construction Business Partnership Agreement
Danish law-governed agreement establishing a partnership between construction industry entities, defining terms, obligations, and operational framework.
find out more
Agreement With Builder For (Construction)
Danish law-governed construction agreement between building owner and contractor, establishing terms for construction project execution and compliance with Danish building regulations.
find out more
Vesting Agreement (Construction)
A legal agreement governing progressive ownership transfer during construction projects under Danish law.
find out more
Build Agreement
Danish law construction contract establishing terms and conditions between employer and contractor under AB 18 framework.
find out more
Novation Agreement (Construction)
A Danish law agreement transferring rights and obligations under a construction contract from an original contractor/consultant to a new one, ensuring project continuity under Danish construction regulations.
find out more
Turnkey Project Agreement
Danish law-governed agreement for complete turnkey project delivery, covering design through commissioning with contractor's full responsibility for operational facility delivery.
find out more
Residential Contractor Agreement
A Danish law-governed agreement between a contractor and homeowner for residential construction or renovation works, incorporating Danish construction and consumer protection requirements.
find out more
Mural Agreement
Danish law-governed agreement for commissioning and installing mural artwork, defining rights and responsibilities between artists and property owners.
find out more
Project Hire Contract
Danish law-governed agreement for project-based employment, defining project scope, deliverables, and employment terms.
find out more
Pipeline Agreement
Danish law-governed agreement for pipeline construction, operation, and maintenance, incorporating local regulatory requirements and EU compliance measures.
find out more
Consortium Partnership Agreement
Danish law-governed agreement establishing and regulating a consortium partnership between multiple organizations, defining collaboration terms and governance structure.
find out more
Building Construction Agreement
Danish law-governed construction agreement establishing terms between building owner and contractor, incorporating AB 18 principles and local building regulations.
find out more
Project Alliance Agreement
A Danish law-governed collaborative agreement establishing a project alliance framework for joint project delivery with shared risks and rewards.
find out more
Project Delivery Agreement
Danish law-governed agreement establishing terms and conditions for project delivery, including scope, deliverables, and party obligations.
find out more
Pilot Project Agreement
Danish law agreement for establishing and governing pilot projects, including scope, responsibilities, and IP rights.
find out more
Minor Works Agreement
A Danish law-governed construction contract for small-scale building projects and renovations, incorporating key principles from Danish construction law and the AB-System.
find out more
Turnkey Contract Agreement
A Danish law-governed agreement for turnkey construction projects, establishing comprehensive terms for design-build project delivery under ABT 18 principles.
find out more
Commercial Supply Agreement
A Danish law-governed agreement establishing terms and conditions for regular commercial supply of goods between supplier and buyer.
find out more
Engineering Procurement And Construction Agreement
Danish law-governed agreement for comprehensive engineering, procurement, and construction projects, detailing contractor obligations and project execution requirements.
find out more
Project Cooperation Agreement
Danish law-governed agreement establishing terms and conditions for multi-party project collaboration, including responsibilities, resources, and rights.
find out more
Project Agreement Contract
Danish law-governed agreement establishing terms and conditions for project execution, including scope, deliverables, timelines, and responsibilities.
find out more
New Construction Agreement
Danish law-governed agreement for new construction projects, incorporating AB 18 requirements and establishing key terms between client and contractor.
find out more
Renovation Agreement
Danish law-governed agreement outlining terms and conditions for property renovation work, including scope, pricing, timeline, and responsibilities.
find out more
Demolition Agreement
Danish law-governed agreement setting terms and conditions for demolition works, including safety, environmental, and regulatory requirements.
find out more
Project Development Agreement
A Danish law-governed agreement between developer and client establishing terms and conditions for property or infrastructure development projects.
find out more
Proof Of Concept Agreement
A Danish law agreement governing the testing and evaluation of new technologies or solutions, establishing terms for proof of concept implementation.
find out more
Pre Construction Agreement
Danish law-governed agreement establishing terms and conditions for pre-construction services between client and contractor.
find out more
Download our whitepaper on the future of AI in Legal
By providing your email address you are consenting to our Privacy Notice.
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
Our bank-grade security infrastructure undergoes regular external audits
We are ISO27001 certified, so your data is secure
Organizational security
You retain IP ownership of your documents
You have full control over your data and who gets to see it
Innovation in privacy:
Genie partnered with the Computational Privacy Department at Imperial College London
Together, we ran a £1 million research project on privacy and anonymity in legal contracts
Want to know more?
Visit our Trust Centre for more details and real-time security updates.
Read our Privacy Policy.