Construction Contract Agreement Template for Denmark

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Construction Contract Agreement

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Construction Contract Agreement

Document background

The Construction Contract Agreement is a fundamental legal document used in Danish construction projects to establish a binding relationship between the employer (building owner) and the contractor. This agreement is essential for any construction project in Denmark, whether it's a commercial building, residential development, or infrastructure project. The document is structured to comply with Danish construction law, particularly incorporating the widely-accepted AB 18 (General Conditions for Building and Construction Works) guidelines. It covers crucial elements including detailed scope of works, payment mechanisms, project timeline, quality standards, risk allocation, and dispute resolution procedures. The agreement should be used whenever engaging a contractor for construction works in Denmark, ensuring all parties understand their rights, obligations, and the project's parameters while maintaining compliance with local regulations and industry standards.

Suggested Sections

1. Parties: Identification and details of the Employer and Contractor, including business registration numbers (CVR)

2. Background: Context of the construction project and the purpose of the agreement

3. Definitions: Definitions of key terms used throughout the agreement, including technical construction terminology

4. Scope of Works: Detailed description of the construction works to be performed, including reference to technical specifications

5. Contract Documents: Hierarchy and list of all documents forming part of the contract, including drawings and specifications

6. Project Timeline: Commencement date, completion date, and key milestone dates

7. Contract Sum and Payment: Price, payment schedule, variation procedures, and handling of cost adjustments

8. Contractor Obligations: Key responsibilities including quality standards, workmanship, and compliance with laws

9. Employer Obligations: Responsibilities including site access, permits, and information provision

10. Site Conditions and Safety: Site management, safety requirements, and environmental protection measures

11. Quality Assurance: Quality control procedures, inspections, and acceptance criteria

12. Variations and Changes: Procedures for handling changes to scope, pricing, and timeline

13. Delays and Extensions: Handling of delays, extension of time procedures, and liquidated damages

14. Defects and Warranties: Defect liability period, warranty terms, and remediation procedures

15. Insurance and Liability: Required insurance coverage and allocation of risks

16. Force Majeure: Definition and consequences of force majeure events

17. Termination: Grounds and procedures for contract termination by either party

18. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration

19. Governing Law: Confirmation of Danish law as governing law and jurisdiction

Optional Sections

1. Performance Security: Requirements for bank guarantees or performance bonds, used for larger projects

2. Intellectual Property Rights: Relevant for projects involving design elements or innovative construction methods

3. Confidentiality: Required for projects involving sensitive information or proprietary construction methods

4. Environmental Requirements: Detailed environmental obligations beyond standard requirements, for environmentally sensitive projects

5. Building Information Modeling (BIM): Specific provisions for projects using BIM technology

6. Subcontracting: Detailed provisions for projects where significant subcontracting is anticipated

7. Materials Supply: Specific provisions for projects where the employer supplies materials

8. Provisional Sums: For projects with uncertain elements requiring provisional pricing

9. Archaeological Findings: For construction in historically sensitive areas

10. Multiple Phase Completion: For projects requiring staged completion and handover

Suggested Schedules

1. Schedule 1: Technical Specifications: Detailed technical requirements and construction specifications

2. Schedule 2: Drawings: Complete set of construction drawings and plans

3. Schedule 3: Price Schedule: Detailed breakdown of contract sum, including unit prices and quantities

4. Schedule 4: Project Timeline: Detailed program of works including milestones and critical path

5. Schedule 5: Quality Assurance Plan: Detailed quality control procedures and acceptance criteria

6. Schedule 6: Site Rules and Safety Procedures: Specific site management and safety requirements

7. Schedule 7: Insurance Requirements: Detailed insurance specifications and certificates

8. Schedule 8: Form of Payment Certificate: Template for payment applications and certificates

9. Schedule 9: Form of Completion Certificate: Template for substantial completion and final completion certificates

10. Schedule 10: List of Approved Subcontractors: Pre-approved subcontractors for specific work packages

Authors

Relevant legal definitions

Agreement
Applicable Laws
Approval
Architect
As-Built Drawings
Authority Requirements
Background IP
Bill of Quantities
Building Permit
Certificate of Completion
Change Order
Commencement Date
Completion Date
Construction Documents
Construction Period
Construction Schedule
Contract Documents
Contract Sum
Contractor
Contractor's Equipment
Defects
Defects Liability Period
Delay Events
Design Documents
Employer
Employer's Requirements
Extension of Time
Final Completion Certificate
Force Majeure
Good Industry Practice
Governing Law
Intellectual Property Rights
Interim Payment Certificate
Key Personnel
Liquidated Damages
Materials
Milestone
Notice
Payment Certificate
Performance Security
Permits
Practical Completion
Project
Project Manager
Quality Assurance Plan
Retention Money
Site
Specifications
Subcontractor
Substantial Completion
Technical Advisor
Time for Completion
Variation
Works
Working Day

Clauses

Relevant Industries

Relevant Teams

Relevant Roles

How Genie AI reduced drafting time by 75% for a legal firm

Let's create your Construction Contract Agreement

Authors

Find the exact document you need

Simple Building Contract

Contract For Independent Consultant

Building Construction Labour Contract Agreement

Standard Independent Contractor Contract

Independent Driver Agreement

Indemnity Agreement (Construction)

Indemnification Agreement (Construction)

Exclusive Subcontractor Agreement

Subcontractor To Subcontractor Agreement

Sole Trader Contract

Painting Contract Agreement

NDA For Subcontractors

Framework Agreement Contract

Contract Between Owner And Architect

Confidentiality Agreement For Contractors

Contract Agreement Between Owner And Contractor

Owner's Representative Agreement

Insurance Agent Independent Contractor Agreement

Model Form Contract

Profit Sharing Agreement Independent Contractor

Loan Officer Independent Contractor Agreement

Job Agreement Contract

House Demolition Contract

Subcontractor Framework Agreement

Software Subcontractor Agreement

Real Estate Agent Agreement Contract

Marketing Contractor Agreement

Independent Contractor Agreement For Transportation Services

Salon Agreement Contract

Owner Agreement Contract

Legal Agreement Contract

House Painting Contract

House Construction Agreement Between Owner Contractor

Contract For Self Employed

Model Agreement Contract

Subcontractor Non Compete Agreement

Project Manager Contract Agreement

Subcontractor Cleaning Contract

Staffing Agreement Contract

Roofing Subcontractor Agreement

Real Estate Agreement Contract

General Service Contract

Liability Agreement Contract

Electrical Contractor Contract

Agency Contractor Agreement

Independent Consultant Contract

Product Agreement Contract

International Independent Contractor Agreement

Independent Consultant Agreement

Outsourcing Contract Agreement

Software Contractor Agreement

Settlement Agreement Contract

Joint Venture Construction Agreement

Contractor Employment Agreement

Remodeling Contractor Agreement

Payment Plan Agreement Contract

General Construction Agreement

Non Disclosure Agreement For Contractors

Partner Agreement Contract

Home Renovation Contract

House Agreement Contract

Subcontractor Agreement

Private Contract

Independent Contractor Consulting Agreement

Independent Contractor Agreement

General Contractor Contract

Construction Contract Agreement

Construction Agreement

Business Agreement Contract

Building Contract Agreement

Download our whitepaper on the future of AI in Legal

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy: