Construction Joint Venture Agreement Template for Austria

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Construction Joint Venture Agreement

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

Construction Joint Venture Agreement

"I need a Construction Joint Venture Agreement under Austrian law for a partnership between my construction company and a foreign contractor to build a large-scale solar power facility, with construction starting in March 2025 and specific provisions for technology transfer and local content requirements."

Document background

The Construction Joint Venture Agreement is essential for parties seeking to collaborate on construction projects in Austria while sharing risks, resources, and expertise. This document is typically used when two or more construction companies, developers, or related entities wish to combine their capabilities for large-scale or complex construction projects. The agreement must comply with Austrian civil law (ABGB), commercial code (UGB), and construction regulations, while addressing specific requirements of the Austrian construction industry. It covers crucial aspects such as capital contributions, profit sharing, governance structure, operational procedures, and risk allocation. The document is particularly important for international joint ventures entering the Austrian market, as it ensures compliance with local construction standards and regulatory requirements while providing a clear framework for project execution and partner collaboration.

Suggested Sections

1. Parties: Identification of the JV partners, including full legal names, registration details, and addresses

2. Background: Context of the joint venture formation and the construction project

3. Definitions and Interpretation: Definitions of key terms and interpretation rules for the agreement

4. Formation of Joint Venture: Legal structure, name, registration requirements, and duration of the JV

5. Purpose and Scope: Detailed description of the construction project and JV objectives

6. Capital Contributions: Partners' initial and ongoing capital contributions, including equipment, personnel, and resources

7. Ownership and Profit Sharing: Partnership percentages, profit/loss allocation, and distribution rules

8. Management and Control: JV governance structure, management board composition, voting rights, and decision-making processes

9. Operations and Project Execution: Day-to-day management, project execution procedures, and operational responsibilities

10. Financial Management: Banking, accounting, auditing, and financial reporting requirements

11. Personnel and Employment: Staffing, employment policies, and labor law compliance

12. Insurance and Liability: Required insurance coverage and allocation of liabilities between partners

13. Confidentiality: Protection of confidential information and trade secrets

14. Term and Termination: Duration, termination events, and wind-up procedures

15. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration provisions

16. Governing Law: Confirmation of Austrian law application and jurisdiction

Optional Sections

1. Intellectual Property Rights: Include when the JV involves significant IP or technology transfer

2. Environmental Compliance: Include for projects with significant environmental impact

3. Public Relations: Include for high-profile projects requiring coordinated public communications

4. Anti-Corruption Compliance: Include for public projects or when required by partners' compliance policies

5. Force Majeure: Include detailed force majeure provisions for long-term or high-risk projects

6. Step-In Rights: Include when project financing requires lender step-in rights

7. Local Content Requirements: Include when project is subject to local content or participation requirements

8. Technology Transfer: Include when JV involves significant technology sharing or transfer between partners

Suggested Schedules

1. Schedule 1 - Project Scope: Detailed description of construction project scope and specifications

2. Schedule 2 - Capital Contributions: Detailed breakdown of each partner's capital and resource contributions

3. Schedule 3 - Project Timeline: Project schedule, milestones, and completion dates

4. Schedule 4 - Budget and Cost Allocation: Detailed project budget and cost sharing mechanism

5. Schedule 5 - Management Structure: Organizational chart and key personnel

6. Schedule 6 - Equipment Schedule: List of equipment to be provided by each partner

7. Schedule 7 - Insurance Requirements: Detailed insurance specifications and coverage requirements

8. Schedule 8 - Quality Control Procedures: Quality assurance and control procedures

9. Appendix A - Form of Project Reports: Templates for required project reporting

10. Appendix B - Construction Permits: Copies of relevant permits and authorizations

11. Appendix C - Technical Specifications: Detailed technical requirements and standards

12. Appendix D - HSE Requirements: Health, safety, and environmental requirements and procedures

Authors

Alex Denne

Head of Growth (Open Source Law) @ Genie AI | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Agreement
Applicable Law
Arbitration
Articles of Association
Austrian Construction Standards
Authorized Representative
Background IP
Board
Business Day
Business Plan
Capital Contribution
Change Order
Commencement Date
Completion Date
Confidential Information
Construction Equipment
Construction Period
Construction Phase
Construction Schedule
Construction Site
Construction Works
Contract Price
Contractor
Defects Liability Period
Deliverables
Design Documents
Dispute
Environmental Laws
Extension of Time
Force Majeure Event
Governing Law
HSE Requirements
Insurance Policies
Intellectual Property Rights
Joint Venture
JV Account
JV Board
JV Manager
JV Partners
Key Personnel
Labor Laws
License
Management Committee
Material Adverse Change
Material Breach
Member
Milestone
Operating Budget
Operating Costs
Parent Company
Party/Parties
Performance Bond
Permits
Project
Project Manager
Project Schedule
Quality Standards
Regulatory Approvals
Related Party
Representatives
Scope of Work
Services
Share
Site
Specifications
Subcontractor
Technical Standards
Term
Termination Event
Third Party
Time for Completion
Variation
Warranty Period
Work Package
Working Capital

Clauses

Relevant Industries

Construction

Real Estate Development

Infrastructure

Commercial Property

Residential Property

Industrial Development

Energy

Transportation

Healthcare Facilities

Education Facilities

Retail Development

Hospitality

Manufacturing

Public Works

Environmental Services

Relevant Teams

Legal

Finance

Operations

Project Management

Risk Management

Commercial

Business Development

Technical

Procurement

Health and Safety

Quality Assurance

Environmental Compliance

Human Resources

Accounting

Corporate Strategy

Regulatory Compliance

Relevant Roles

Chief Executive Officer

Managing Director

Construction Project Manager

Legal Counsel

Contract Manager

Chief Financial Officer

Operations Director

Technical Director

Risk Manager

Commercial Director

Business Development Manager

Chief Operating Officer

Joint Venture Manager

Construction Site Manager

Procurement Manager

Health and Safety Manager

Quality Assurance Manager

Environmental Compliance Manager

Human Resources Director

Financial Controller

Find the exact document you need

Venture Capital General Partner Agreement

An Austrian law-governed agreement establishing the relationship between a general partner and a venture capital fund, including rights, duties, and economic terms.

How a Sales & Marketing Lead uses Genie AI to reduce contract drafting time by 95%

Let's create your Construction Joint Venture Agreement

Authors

Alex Denne

Find the exact document you need

Venture Capital General Partner Agreement

Alliance Agreement

Memorandum Of Understanding For Partnership

Limited Partners Agreement

Reseller Partnership Agreement

Business Partnership Percentage Agreement

Limited Liability Partnership Contract

Short Partnership Agreement

Social Media Partnership Agreement

Partnership Deed

Simple General Partnership Agreement

Memorandum Of Understanding Collaboration

Venture Partner Agreement

Technology Partnership Agreement

Startup Partnership Agreement

Software Partnership Agreement

Software Partner Agreement

Shareholders Agreement Joint Venture

Revenue Share Partnership Agreement

Real Estate Joint Venture Agreement

Preferred Partnership Agreement

Preferred Partner Agreement

Partnership Framework Agreement

Partnership Contract Agreement

Long Term Partnering Agreement

Limited Partnership Agreement

Letter Of Intent Joint Venture

Letter Of Intent Strategic Partnership

Joint Partnership Agreement

Informal Partnership Agreement

Channel Partner Agreement

Business Collaboration Contract

50 50 Partnership Agreement

Joint Venture Agreement Between Two Companies

General Partnership Contract

Simple Joint Venture Agreement

Marketing Partnership Agreement

Construction Joint Venture Agreement

Joint Venture Memorandum Of Understanding

Limited Partnership Agreement Private Equity

Download our whitepaper on the future of AI in Legal

Genie’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy:

Want to know more?

Commercial

Employment

IP

Administration

Finance

R&D

Use Cases