The Builder Buyer Agreement is a crucial document in Qatar's construction and real estate sector, used when a builder or developer agrees to construct a property for a buyer. This agreement is essential for both residential and commercial construction projects in Qatar, where it must comply with the Qatar Civil Code, local building regulations, and municipal requirements. The document typically includes comprehensive details about construction specifications, payment schedules, quality standards, completion timelines, and warranty terms. It serves as the primary contract governing the relationship between the builder and buyer throughout the construction process, from groundbreaking to final handover. The agreement must incorporate specific provisions required under Qatari law, including those related to building permits, environmental compliance, and technical standards set by local authorities.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Identification and details of the Builder/Developer and the Buyer, including their legal status and contact information
2. Background: Context of the agreement, including property details and purpose of construction
3. Definitions: Detailed definitions of terms used throughout the agreement
4. Scope of Work: Detailed description of the construction work to be performed, including specifications and standards
5. Contract Price and Payment Terms: Total contract value, payment schedule, and payment mechanisms
6. Construction Timeline: Project schedule, milestones, and completion dates
7. Builder's Obligations: Comprehensive list of builder's responsibilities, including quality standards and compliance requirements
8. Buyer's Obligations: Buyer's responsibilities including payment, access, and cooperation requirements
9. Quality and Standards: Construction quality requirements and applicable building standards
10. Variations and Changes: Process for handling changes to scope, specifications, or design
11. Inspections and Approvals: Procedures for construction inspections and obtaining necessary approvals
12. Handover Process: Requirements and procedures for project completion and property handover
13. Defects Liability: Warranty terms and defect rectification obligations
14. Insurance and Indemnity: Insurance requirements and indemnification provisions
15. Default and Termination: Events of default, remedies, and termination procedures
16. Dispute Resolution: Procedures for resolving disputes, including arbitration provisions
17. Force Majeure: Provisions for handling unforeseen circumstances and their impact
18. Governing Law: Specification of Qatar law as governing law and jurisdiction
19. Notices: Communication procedures and contact details for formal notices
20. General Provisions: Standard boilerplate clauses including assignment, severability, and entire agreement
1. Environmental Compliance: Specific environmental requirements and compliance measures, included for projects with significant environmental impact
2. Sustainable Building Practices: Green building standards and sustainability requirements, included for projects seeking environmental certification
3. Utilities and Infrastructure: Specific provisions for utility connections and infrastructure development, included for projects requiring significant utility work
4. Security Arrangements: Requirements for site security and safety measures, included for large-scale projects
5. Subcontracting: Terms governing the appointment and management of subcontractors, included when subcontracting is anticipated
6. Intellectual Property Rights: Provisions regarding design rights and other IP, included for projects with unique architectural designs
7. Marketing and Promotion: Terms regarding project marketing and promotional activities, included for commercial developments
8. Maintenance Period: Extended maintenance obligations beyond standard warranty, included when long-term maintenance is part of the deal
1. Schedule 1 - Property Details: Detailed description of the property including location, dimensions, and title details
2. Schedule 2 - Construction Specifications: Detailed technical specifications, materials, and construction methods
3. Schedule 3 - Payment Schedule: Detailed breakdown of payment installments and milestone linkages
4. Schedule 4 - Construction Timeline: Detailed project schedule with milestones and completion dates
5. Schedule 5 - Approved Drawings: Architectural, structural, and other technical drawings
6. Schedule 6 - Quality Standards: Detailed quality specifications and acceptance criteria
7. Schedule 7 - Forms and Certificates: Standard forms for variations, completion certificates, and other documents
8. Schedule 8 - Permits and Approvals: List of required permits and responsibilities for obtaining them
9. Appendix A - Site Plan: Detailed site plan and layout drawings
10. Appendix B - Material Specifications: Detailed specifications for construction materials
11. Appendix C - Warranty Terms: Detailed warranty terms and conditions
12. Appendix D - Insurance Requirements: Detailed insurance specifications and coverage requirements
Relevant legal definitions
Agreement
Applicable Laws
Approved Drawings
Architect
Building Permit
Builder
Business Day
Buyer
Certificate of Completion
Change Order
Commencement Date
Completion Date
Construction Schedule
Construction Site
Contract Price
Contractor
Defects Liability Period
Delay
Design Documents
Effective Date
Environmental Requirements
Extension of Time
Final Completion
Force Majeure Event
Good Industry Practice
Governing Law
Handover
Intellectual Property Rights
Material Breach
Milestone
Municipality
Notice
Payment Schedule
Permits
Project
Project Manager
Property
Quality Standards
Regulatory Authorities
Schedule of Works
Scope of Work
Site Plan
Specifications
Subcontractor
Substantial Completion
Technical Specifications
Termination Date
Utilities
Variation
Warranty Period
Work
Applicable Laws
Approved Drawings
Architect
Building Permit
Builder
Business Day
Buyer
Certificate of Completion
Change Order
Commencement Date
Completion Date
Construction Schedule
Construction Site
Contract Price
Contractor
Defects Liability Period
Delay
Design Documents
Effective Date
Environmental Requirements
Extension of Time
Final Completion
Force Majeure Event
Good Industry Practice
Governing Law
Handover
Intellectual Property Rights
Material Breach
Milestone
Municipality
Notice
Payment Schedule
Permits
Project
Project Manager
Property
Quality Standards
Regulatory Authorities
Schedule of Works
Scope of Work
Site Plan
Specifications
Subcontractor
Substantial Completion
Technical Specifications
Termination Date
Utilities
Variation
Warranty Period
Work
Clauses
Interpretation
Scope of Work
Construction Standards
Payment Terms
Project Timeline
Builder Obligations
Buyer Obligations
Quality Control
Site Access
Health and Safety
Environmental Compliance
Variations
Force Majeure
Insurance
Indemnification
Warranties
Defects Liability
Intellectual Property
Confidentiality
Dispute Resolution
Termination
Assignment
Subcontracting
Notices
Governing Law
Site Security
Materials and Equipment
Testing and Inspection
Completion and Handover
Permits and Approvals
Utilities and Services
Risk Allocation
Documentation
Records and Reporting
Performance Security
Default Events
Remedies
Liability Limitations
Compliance with Laws
Change Management
Project Management
Quality Assurance
Site Conditions
Construction Methods
Technical Specifications
Measurement and Pricing
Progress Monitoring
Delay Damages
Suspension Rights
Scope of Work
Construction Standards
Payment Terms
Project Timeline
Builder Obligations
Buyer Obligations
Quality Control
Site Access
Health and Safety
Environmental Compliance
Variations
Force Majeure
Insurance
Indemnification
Warranties
Defects Liability
Intellectual Property
Confidentiality
Dispute Resolution
Termination
Assignment
Subcontracting
Notices
Governing Law
Site Security
Materials and Equipment
Testing and Inspection
Completion and Handover
Permits and Approvals
Utilities and Services
Risk Allocation
Documentation
Records and Reporting
Performance Security
Default Events
Remedies
Liability Limitations
Compliance with Laws
Change Management
Project Management
Quality Assurance
Site Conditions
Construction Methods
Technical Specifications
Measurement and Pricing
Progress Monitoring
Delay Damages
Suspension Rights
Relevant Industries
Construction
Real Estate Development
Property Development
Infrastructure
Residential Construction
Commercial Construction
Industrial Construction
Architectural Services
Engineering Services
Property Investment
Relevant Teams
Legal
Construction
Project Management
Real Estate
Procurement
Finance
Compliance
Risk Management
Technical Services
Quality Assurance
Business Development
Operations
Relevant Roles
Construction Manager
Project Director
Real Estate Developer
Property Manager
Contract Manager
Legal Counsel
Architect
Civil Engineer
Quantity Surveyor
Development Manager
Construction Site Manager
Compliance Officer
Risk Manager
Technical Director
Financial Controller
Procurement Manager
Find the exact document you need
Unilateral Contract (Real Estate)
A Qatar law-governed unilateral real estate contract establishing binding property transfer terms upon specified performance by the accepting party.
find out more
Standard Form Of Contract In (Construction)
A standard form construction contract compliant with Qatari law, providing a comprehensive framework for construction projects in Qatar.
find out more
Wholesaling Real Estate Contract
A Qatar-law governed wholesale real estate contract template for bulk property transactions, incorporating local regulatory requirements and commercial practices.
find out more
Non Binding Contract
A non-binding agreement under Qatari law that formally documents parties' intentions and preliminary arrangements without creating legal obligations.
find out more
Partnership Agreement In Written Form
A Qatar law-governed agreement establishing a formal business partnership, defining partners' rights, obligations, and operational framework.
find out more
Option Contract (Real Estate)
A Qatar-law governed agreement granting the exclusive right to purchase specified real estate property within a set timeframe and price.
find out more
Professional Services Agreement
A Qatar law-governed agreement defining terms and conditions for professional services provision, including scope, payment, and legal obligations between service provider and client.
find out more
Unregistered Sale Agreement With Possession
A Qatar law-governed agreement for unregistered property sale and possession transfer, detailing terms, conditions, and parties' rights and obligations.
find out more
House Rent Agreement Form
A Qatar law-governed agreement establishing terms and conditions for residential property rental, compliant with Law No. 4 of 2008 and local regulations.
find out more
Bilateral Contract
Qatar law-compliant bilateral contract template for establishing legally binding agreements between two parties, aligned with local legal requirements and business practices.
find out more
Basic Ordering Agreement
Qatar-law governed framework agreement establishing terms and conditions for future procurement orders between parties.
find out more
Consignment Agreement Form
A Qatar-law governed agreement establishing terms for consignment arrangements, where goods are entrusted for sale while ownership remains with the consignor until sold.
find out more
Registered Rent Agreement
A legally binding rental agreement registered with Qatar authorities that establishes terms and conditions between landlord and tenant under Qatar law.
find out more
Tenancy Agreement Form
A Qatar law-compliant agreement establishing terms and conditions for property rental between landlord and tenant, governed by Law No. 4 of 2008.
find out more
General Tenancy Agreement
A Qatar law-governed agreement establishing terms and conditions for property rental, compliant with Law No. 4 of 2008 and local property regulations.
find out more
Standard Form Contract
Qatar-law compliant standard form contract template for recurring business transactions, incorporating local legal requirements and Sharia principles.
find out more
Legal Agreement Between Two Parties
A Qatar law-compliant legal agreement template for establishing formal contractual relationships between two parties, incorporating local legal requirements and Sharia principles.
find out more
Contract Agreement Form
A Qatar law-governed Contract Agreement Form providing a standardized framework for legally binding business agreements in Qatar.
find out more
Terms And Conditions For Rental Agreement
Qatar-governed rental terms and conditions document outlining landlord and tenant rights, responsibilities, and obligations under Qatar Rent Law.
find out more
Simple Agreement
A basic contractual template compliant with Qatar law, suitable for straightforward business arrangements and general commercial use.
find out more
Side Agreement
A Qatar law-governed supplementary contract that modifies or adds to an existing main agreement's terms, ensuring compliance with local civil law requirements while addressing specific business needs.
find out more
Mutual Agreement Between Two Parties
Qatar law-governed mutual agreement template establishing formal rights and obligations between two parties under Qatar Civil Code.
find out more
Lease Agreement With Option To Purchase
A Qatar-law governed agreement combining property lease terms with a future purchase option, compliant with local real estate regulations and civil code requirements.
find out more
Incorporation Agreement
A Qatar law-governed agreement establishing a new company's structure, shareholding, and governance framework in compliance with local regulations.
find out more
Casual Worker Contract
A Qatar-law governed Casual Worker Contract establishing flexible employment terms in compliance with local labor regulations.
find out more
Boilerplate Agreement
A standard agreement template compliant with Qatar law, providing a foundational legal framework for business relationships and transactions.
find out more
Residential Tenancy Agreement Standard Form Of Lease
A standardized residential lease agreement compliant with Qatar law, establishing terms and conditions for property rental between landlord and tenant.
find out more
Representation Agreement
Qatar-law governed agreement establishing and regulating a formal representation relationship between a principal and their appointed representative.
find out more
Preliminary Agreement
A Qatar law-governed framework document establishing preliminary terms and conditions for business negotiations, incorporating local legal requirements and business practices.
find out more
Notary Rent Agreement
A Qatar-compliant notarized rental agreement establishing legally binding terms between landlord and tenant, authenticated according to Qatar law.
find out more
Non Compete Agreement Between Companies
A Qatar law-governed Non-Compete Agreement restricting competitive activities between companies, ensuring compliance with Qatari commercial and competition laws.
find out more
Lease With Option To Buy
Qatar-governed agreement combining property lease terms with a future purchase option, compliant with local property laws and regulations.
find out more
Land Agreement Between Two Parties
A Qatar law-governed agreement facilitating land transfer or rights between two parties, ensuring compliance with local property regulations and registration requirements.
find out more
Contract Agreement Between Two Parties
A legally binding agreement between two parties that establishes contractual relationships under Qatar law, outlining mutual rights and obligations.
find out more
Common Terms Agreement
Qatar law-governed agreement establishing standardized terms for syndicated financing transactions, harmonizing multiple facility agreements under a single framework.
find out more
Labour Contract Copy
A legally compliant employment agreement under Qatar Labor Law that establishes the terms and conditions of employment between an employer and employee in Qatar.
find out more
Enforceable Contract
A legally binding agreement governed by Qatari law that establishes enforceable rights and obligations between parties, compliant with Qatar Civil Code requirements.
find out more
Employee Agreement Form
A Qatar-compliant employment agreement establishing terms and conditions of employment under Qatar Labor Law, suitable for both local and expatriate employees.
find out more
Statement Of Agreement
A formal document under Qatar law that records mutual understanding and agreed terms between parties, ensuring compliance with local legal requirements and Sharia principles.
find out more
Work Agreement Between Two Parties
Qatar-law compliant employment agreement establishing terms and conditions between employer and employee, incorporating local labor law requirements.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)