The Contract For Construction Work is a fundamental legal document used in the Indian construction industry to establish a binding agreement between property owners/developers and construction contractors. This document is essential for any construction project in India, whether it's a residential, commercial, or infrastructure development. The contract ensures compliance with Indian construction laws, including the Building and Other Construction Workers Act, 1996, and relevant state regulations. It typically includes detailed specifications for the construction work, payment terms, project timelines, quality standards, and safety requirements. The document also addresses crucial aspects such as labor welfare, environmental compliance, and dispute resolution mechanisms as required under Indian law. This type of contract is particularly important as it provides legal protection to all parties involved and ensures clear documentation of responsibilities, risks, and obligations throughout the construction project lifecycle.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
Upload your Doc
1. Parties: Details of the employer/owner and the contractor, including registered addresses and company registration numbers
2. Background: Context of the construction project and the purpose of the agreement
3. Definitions: Definitions of key terms used throughout the contract
4. Scope of Work: Detailed description of the construction work to be performed
5. Contract Price: Total contract value, payment terms, and payment schedule
6. Project Timeline: Construction schedule, milestones, and completion dates
7. Contractor's Obligations: Responsibilities and duties of the contractor including quality standards, safety measures, and compliance requirements
8. Employer's Obligations: Responsibilities of the employer including site access, permits, and approvals
9. Materials and Workmanship: Standards for materials, quality requirements, and workmanship specifications
10. Variations and Changes: Process for handling changes to scope, specifications, or contract terms
11. Insurance and Indemnity: Insurance requirements and indemnification obligations
12. Defects Liability: Defects liability period and remediation process
13. Performance Security: Requirements for performance bank guarantee or security deposit
14. Site Conditions: Site access, working conditions, and site management requirements
15. Force Majeure: Provisions for unforeseen circumstances and their handling
16. Termination: Grounds and process for contract termination
17. Dispute Resolution: Process for resolving disputes including arbitration provisions
18. Governing Law: Applicable laws and jurisdiction
1. Environmental Compliance: Required for projects with significant environmental impact, detailing environmental protection measures
2. Labor Welfare: Detailed provisions for labor welfare when project involves significant workforce
3. Subcontracting: Include when subcontracting is permitted, specifying terms and conditions
4. Equipment and Machinery: Required for projects involving significant use of equipment and machinery
5. Technology and Intellectual Property: Include for projects involving specialized technology or design elements
6. Safety Management: Detailed safety protocols for high-risk construction projects
7. Quality Assurance Program: Detailed quality control measures for complex projects
8. Site Security: Required for projects in sensitive locations or requiring special security measures
1. Schedule A - Scope of Work: Detailed technical specifications and drawings
2. Schedule B - Bill of Quantities: Itemized list of work items with quantities and rates
3. Schedule C - Payment Schedule: Detailed payment terms, milestones, and payment breakdown
4. Schedule D - Project Timeline: Detailed construction schedule with milestones
5. Schedule E - Site Plan: Site layout, access points, and working areas
6. Schedule F - Material Specifications: Detailed specifications for construction materials
7. Schedule G - Quality Standards: Quality requirements and testing procedures
8. Schedule H - Safety Requirements: Safety protocols and procedures
9. Appendix 1 - Required Permits and Approvals: List of necessary permits and responsibilities
10. Appendix 2 - Insurance Requirements: Detailed insurance coverage requirements
11. Appendix 3 - Form of Performance Security: Format for bank guarantee or performance bond
12. Appendix 4 - Key Personnel: List of key personnel from both parties with roles and responsibilities
Relevant legal definitions
Agreement
Applicable Laws
Approved
Architect
As-Built Drawings
Bill of Quantities
Commencement Date
Completion Certificate
Construction Documents
Construction Equipment
Contract Price
Contract Period
Contractor
Contractor's Personnel
Day
Defects
Defects Liability Period
Drawings
Employer
Employer's Representative
Extension of Time
Final Completion Certificate
Force Majeure
Good Industry Practice
Governmental Authority
Letter of Award
Material Breach
Milestone
Notice
Payment Certificate
Performance Security
Project
Project Manager
Project Site
Quality Assurance Plan
Retention Money
Schedule of Rates
Scope of Work
Site
Specifications
Sub-contractor
Substantial Completion
Technical Specifications
Temporary Works
Time for Completion
Variation
Virtual Completion
Work Order
Works
Applicable Laws
Approved
Architect
As-Built Drawings
Bill of Quantities
Commencement Date
Completion Certificate
Construction Documents
Construction Equipment
Contract Price
Contract Period
Contractor
Contractor's Personnel
Day
Defects
Defects Liability Period
Drawings
Employer
Employer's Representative
Extension of Time
Final Completion Certificate
Force Majeure
Good Industry Practice
Governmental Authority
Letter of Award
Material Breach
Milestone
Notice
Payment Certificate
Performance Security
Project
Project Manager
Project Site
Quality Assurance Plan
Retention Money
Schedule of Rates
Scope of Work
Site
Specifications
Sub-contractor
Substantial Completion
Technical Specifications
Temporary Works
Time for Completion
Variation
Virtual Completion
Work Order
Works
Clauses
Scope of Work
Contract Price
Payment Terms
Project Timeline
Quality Control
Materials and Workmanship
Site Access and Conditions
Health and Safety
Environmental Compliance
Labor Welfare
Insurance
Indemnification
Performance Security
Warranties
Variations
Force Majeure
Termination
Dispute Resolution
Governing Law
Confidentiality
Assignment and Subcontracting
Intellectual Property
Permits and Approvals
Testing and Inspection
Defects Liability
Completion and Handover
Liquidated Damages
Risk Allocation
Representations and Warranties
Notices
Record Keeping
Compliance with Laws
Security
Equipment and Machinery
Project Management
Change Management
Contract Price
Payment Terms
Project Timeline
Quality Control
Materials and Workmanship
Site Access and Conditions
Health and Safety
Environmental Compliance
Labor Welfare
Insurance
Indemnification
Performance Security
Warranties
Variations
Force Majeure
Termination
Dispute Resolution
Governing Law
Confidentiality
Assignment and Subcontracting
Intellectual Property
Permits and Approvals
Testing and Inspection
Defects Liability
Completion and Handover
Liquidated Damages
Risk Allocation
Representations and Warranties
Notices
Record Keeping
Compliance with Laws
Security
Equipment and Machinery
Project Management
Change Management
Relevant Industries
Construction
Real Estate
Infrastructure
Commercial Property
Residential Property
Industrial Development
Urban Development
Public Works
Engineering Services
Architecture
Relevant Teams
Legal
Operations
Construction
Project Management
Finance
Procurement
Risk Management
Compliance
Quality Assurance
Health and Safety
Technical
Commercial
Development
Relevant Roles
Construction Manager
Project Manager
Site Engineer
Contract Manager
Legal Counsel
Procurement Manager
Chief Financial Officer
Operations Director
Risk Manager
Compliance Officer
Quality Assurance Manager
Health and Safety Officer
Technical Director
Commercial Manager
Development Manager
Construction Director
Quantity Surveyor
Architect
Structural Engineer
Find the exact document you need
Lease Agreement Form
An Indian law-compliant agreement establishing terms and conditions between property owner and tenant for the rental of residential or commercial property.
find out more
Evergreen Contract
An automatically renewing contract template compliant with Indian law, designed for ongoing business relationships.
find out more
Contract For Deed
An Indian law-compliant agreement where property is sold through installment payments, with the seller retaining title until full payment is received.
find out more
Bespoke Contract
A customized legal agreement tailored to specific business requirements under Indian law, incorporating both mandatory legal provisions and specialized commercial terms.
find out more
Supplementary Agreement
An Indian law-governed document that modifies or adds to an existing agreement while maintaining its core structure and legal framework.
find out more
Public Contract
An Indian law-governed agreement between a government entity and private party for public procurement, following government procurement regulations and compliance requirements.
find out more
Partnership Agreement In Written Form
A legally binding agreement under Indian law that establishes a partnership between two or more parties, defining their rights, responsibilities, and business relationship.
find out more
Business Agreement
A legally binding business agreement under Indian law establishing commercial relationships between parties, incorporating key provisions and compliance requirements.
find out more
Warrant Agreement
An Indian law-governed agreement establishing terms for issuance and exercise of warrants, complying with SEBI regulations and Companies Act requirements.
find out more
Triple Net Lease Agreement
An Indian law-governed lease agreement where the tenant is responsible for property taxes, insurance, and maintenance costs in addition to rent.
find out more
Surety Agreement
An Indian law-governed agreement where a surety guarantees the payment or performance obligations of a principal debtor to a creditor.
find out more
Subscription Agreement
An Indian law-governed agreement establishing terms for recurring access to products or services, defining rights and obligations of service providers and subscribers.
find out more
Sub Tenancy Agreement
An Indian law-compliant agreement allowing a tenant to lease their rented property to another party, subject to state-specific regulations and original lease terms.
find out more
Short Term Contract
An Indian law-governed contract for temporary employment relationships, establishing terms and conditions for fixed-duration engagements while ensuring compliance with local labor regulations.
find out more
Scheduling Agreement
An Indian law-governed framework agreement establishing terms for scheduled, recurring deliveries of goods or services with predetermined quantities and timelines.
find out more
Probationary Contract
An Indian law-governed employment agreement establishing terms for a probationary period of employment, including conditions for permanent confirmation.
find out more
Purchase Proposal
A formal document under Indian law outlining a buyer's intent to purchase specific goods or services, including key terms and conditions.
find out more
Novation Agreement (Real Estate)
An Indian law-governed agreement transferring rights and obligations under an existing real estate contract from one party to another, with the consent of all parties involved.
find out more
Novation Agreement
An Indian law-governed tripartite agreement that transfers contractual rights and obligations from one party to another, with all parties' consent.
find out more
Option Contract (Real Estate)
An Indian law-governed agreement granting exclusive rights to purchase specified real estate property within a set timeframe and price.
find out more
Material Contract
An Indian law-governed agreement establishing terms for material supply, including specifications, quality standards, and delivery terms.
find out more
Labor Contract
An Indian law-compliant employment agreement establishing terms and conditions between employer and employee.
find out more
Lease Deed
An Indian law-compliant legal document establishing terms and conditions for leasing property between a lessor and lessee.
find out more
Informal Contract
Template for creating simple, legally valid informal contracts under Indian law, suitable for small businesses and freelancers.
find out more
Individual Contract
An Indian law-governed employment contract establishing terms and conditions between employer and employee, ensuring compliance with local labor laws.
find out more
Franchise Agreement
An Indian law-governed agreement establishing a franchise relationship, granting business operation rights under the franchisor's brand and system.
find out more
Form For Independent Contractor
Standard Indian law-compliant Independent Contractor Agreement template for establishing and managing independent service provider relationships.
find out more
Encroachment Agreement
An Indian law-compliant agreement that resolves property encroachment issues between parties, establishing rights and obligations regarding the encroached property.
find out more
Executive Contract
An Indian law-governed employment agreement for executive positions, defining terms of employment, duties, compensation, and obligations in compliance with Indian corporate and labor laws.
find out more
Contingency Contract
An Indian law-governed Contingency Contract establishing obligations dependent on specified future uncertain events, structured under the Indian Contract Act, 1872.
find out more
Consent Agreement
An Indian law-compliant agreement documenting explicit consent for personal data collection and processing, ensuring legal data handling practices.
find out more
Business To Business Contract
An Indian law-governed contract template for establishing commercial relationships between business entities, ensuring compliance with Indian contract law and commercial regulations.
find out more
Barter Agreement
An Indian law-governed agreement facilitating the direct exchange of goods/services between parties without monetary consideration.
find out more
Master Contract
An Indian law-governed framework agreement that establishes standard terms and conditions for future specific agreements between parties.
find out more
Notarial Contract
An Indian law-governed contract formally authenticated by a licensed notary public, providing enhanced legal certainty and evidentiary value.
find out more
Basic Ordering Agreement
An Indian law-governed master agreement establishing terms and conditions for future orders between parties, streamlining recurring business transactions.
find out more
Guarantee Contract
An Indian law-governed contract where a guarantor undertakes to fulfill another party's obligations to a beneficiary upon default.
find out more
Tenancy Agreement Form
An Indian law-compliant agreement establishing terms and conditions between landlord and tenant for property rental, incorporating relevant state and central legislation requirements.
find out more
General Tenancy Agreement
An Indian law-compliant agreement establishing terms and conditions for property rental between landlord and tenant, governed by Indian property legislation and state-specific regulations.
find out more
Contract Agreement Form
A standardized contract agreement template compliant with Indian law, establishing legally binding terms between parties.
find out more
Genie’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; Genie’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)
.png)