1. Parties: Identification and details of the Principal (Bauherr) and Contractor (Auftragnehmer), including registration numbers and authorized representatives
2. Background: Brief description of the project context and purpose of the agreement
3. Definitions: Definitions of key terms used throughout the contract, including technical construction terminology
4. Scope of Works: Detailed description of the construction works to be performed, including specifications and standards to be met
5. Project Timeline: Construction schedule, milestones, completion dates, and any phase-specific deadlines
6. Contract Price and Payment Terms: Agreed price, payment schedule, variations, retention amounts, and invoicing procedures
7. Contractor Obligations: Key responsibilities including quality standards, material procurement, workforce management, and safety measures
8. Principal Obligations: Responsibilities of the Principal including site access, permits, approvals, and information provision
9. Site Management: Rules for site access, security, storage, waste management, and coordination with other contractors
10. Quality Control: Quality assurance procedures, inspections, testing requirements, and acceptance criteria
11. Health and Safety: Safety requirements, risk management, and compliance with BauKG and ASchG
12. Insurance and Liability: Required insurance coverage, liability provisions, and indemnification obligations
13. Warranties: Warranty periods, defect rectification procedures, and guarantee obligations
14. Variations and Changes: Procedures for handling changes to scope, specifications, or contract terms
15. Force Majeure: Provisions for unforeseen circumstances and their impact on contract obligations
16. Termination: Grounds and procedures for contract termination, including consequences and settlements
17. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration provisions
18. Governing Law: Confirmation of Austrian law application and jurisdiction
